545 Central Office Equipment Contract (not including install

P & S SERIAL NO.

Central Office Equipment
Contract
(Not Including Installation)

RUS Contract Form 545

U.S. Department of Agriculture
Rural Utilities Service

According to the Paperwork Reduction Act of 1995, an agency may not conduct or sponsor, and a person is not required to respond to, a
collection of information unless it displays a valid OMB control number. The valid OMB control number for this information collection is 05720059. The time required to complete this information collection is estimated to average 4 hours per response, including the time for reviewing
instruction, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of
information.

RUS Form 545 REV 11-99

Expires: XX/XX/20XX

(Page left intentionally blank)

Page 2

NOTICE AND INSTRUCTIONS TO BIDDERS
CENTRAL OFFICE EQUIPMENT PROJECT
(Not Including Installation)
1. Sealed proposals for the engineering, furnishing, and delivery of central office
equipment, materials, and software for the
(hereinafter called the "Owner") which is to be part of the system known as
to be financed pursuant to a loan contract between the Owner and the United States of America
(hereinafter called the "Government") by the Administrator (hereinafter called the
"Administrator") of the Rural Utilities Service (hereafter called "RUS") will be received by the
M.,
, at
Owner on or before
o'clock,

at which time and place the proposals will be publicly opened and read. The Rural Telephone
Bank may also be a party to the loan contract.
2. The Bid Documents (composed of plans, specifications, and drawings), together with
all necessary forms and other documents for bidders, may be obtained from the Owner or from
the Owner's Engineer, (hereinafter called the "Engineer") at the latter's office at

The Specifications may be examined at the office of the Owner or at the office of the Engineer.
A copy of the loan contract between the Owner and the Government may be examined at the
office of the Owner.
Each set of Bid Documents will have a serial number, assigned by the Engineer, and the number
with the name of the bidder will be recorded by the Engineer. Bids will be accepted only from
original bidders, or other qualified bidder to whom such a set has been transferred by the original
bidder with the approval of the Engineer prior to the pre-bid technical session.
3. A pre-bid technical session will be held with each bidder during the week of
(year), at
for the purpose of receiving the bidder's technical proposal, discussing details of the Project, and
considering suggestions from bidders. The Owner shall attach to this Notice a list of the
information required in the bidder's technical proposal. Each bidder will be given a specific time
period for the pre-bid technical session. At the pre-bid technical session, the bidder shall fully
describe to the Owner any exceptions to the Specifications the bidder may request. In addition,
the bidder shall identify all features and capabilities that are not fully developed or do not have a
verifiable satisfactory field performance record. If the Owner decides to incorporate any changes
into the Specifications, the Owner shall furnish all prospective bidders a copy of the
Specifications containing such revisions (the "Revised Specifications") and all bids shall be
made on the basis of the Revised Specifications. At this session, the bidder shall identify all
documentation and

RUS Form 545 REV 11-99

Page 3

materials that it claims constitute agreed excluded documentation under Section (2)(xi) of the
Software License. The bidder shall claim only those items it may be unable to provide to the
Owner as required by said (2)(xi). The Engineer shall immediately provide a list of all items so
identified to the [appropriate RUS Area office]. The Engineer shall inform the bidder at least
days before the scheduled bid opening whether either the Engineer or [RUS] will reject
the bid because of items so identified. Licensor agrees that certain Licensed Software cannot be
excluded from the requirements of Section (2)(xi), including but not limited to, software, the
absence or improper operation of which would significantly impair the operation of the system,
would significantly impair the ability of the Owner to generate revenue, or would pose a risk to
RUS loan security. If allowed, the agreed excluded documentation shall be individually
identified in an attachment to the bid. No bid shall be accepted from a bidder who fails to attend
the pre-bid technical session or fails to demonstrate to the Owner that its equipment meets the
requirements of the Plans and Specifications.
4. Proposals shall be submitted on the forms furnished by the Owner and must be
delivered in a sealed envelope addressed to the Owner. The name and address of the bidder, its
license number, if a license is required for bidding on a project by the State, and the date and
hour of the opening of bids must appear on the envelope in which the proposal is submitted.
Proposals must be in ink or typewritten. No alterations or interlineations will be permitted,
unless made, initialed, and dated before submission.
5. Prior to the submission of the proposal, the bidder shall make and shall be deemed to
have made a careful examination of the Specifications, forms of bidder's proposal and
acceptance, and shall become informed as to the location and characteristics of the proposed
central office and remote terminal features and services, the transportation facilities, the kind of
facilities required before and during the delivery of the equipment and materials, the general
local conditions and all other matters that may affect the cost. Bidders will be required to comply
with all applicable statutes, codes, and regulations, including those pertaining to the licensing of
contractors and the "Anti Kick-Back Acts," as amended, (40 U.S.C. 276c; 41 U.S.C. 51 et seq.)
and regulations issued pursuant thereto, and 18 U.S.C. 287, 874, 1001.
6. If requested by the Owner or the Administrator, the bidder shall furnish evidence,
satisfactory to the Owner and the Administrator, that the bidder has the necessary facilities,
ability, and financial resources to perform the Contract.
7. The Contract, when executed, shall be deemed to include the entire agreement
between the parties thereto and neither party shall claim any modification thereof resulting from
any representation or promise made at any time by any officer, agent, or employee of the other or
by any other person.
8. The Owner reserves the right to waive minor irregularities or minor errors in any
proposal, if it appears to the Owner that such irregularities or errors were made through
inadvertence. Any such irregularities or errors so waived must be corrected on the proposal in
which they occur prior to the execution of any Contract, which may be awarded thereon.
9. The Owner reserves the right to reject any or all proposals.

RUS FORM 545 REV 11-99

Page 4

10. The equipment to be furnished for all central offices and remote switching terminals
included in the proposal is to be of the same basic design. A proposal submitted on any other
basis will not be considered.
11. Equal Opportunity and Employment
(a) The Offeror's or Bidder's attention is called to the "Equal Opportunity Clause" and
the "Standard Federal Equal Employment Specifications" contained herein.
(b) The goals and timetables for minority and female participation are available from the
Office of Federal Contract Compliance Programs (OFCCP) which has the sole responsibility for
enforcing Executive Order 11246, as amended.
The goals set forth in Executive Order 11246, as amended, are applicable to all the
Contractor's construction work (whether or not it is federal or federally assisted) performed in
the covered area. If the Contractor performs construction work in a geographical area located
outside of the covered area, it shall apply the goals established for such geographical area where
work is actually performed. With regard to this second area, the Contractor also is subject to the
goals for both its federally involved and nonfederally involved construction.
The Contractor's compliance with Executive Order 11246, as amended, and the
implementing regulations at 41 CFR Part 60-4 shall be based on its implementation of the Equal
Opportunity Clause.
(c) The Contractor shall provide written notification to the Director of the Office of
Federal Contract Compliance Programs within 10 working days of award of any construction
subcontract in excess of $10,000 at any tier for construction work under the contract resulting
from this solicitation. The notification shall list the name, address, and telephone number of the
subcontractor; employer identification number of the subcontractor; estimated dollar amount of
the subcontract; estimated starting and completion dates of the subcontract; and, the
geographical area in which the subcontract is to be performed.

RUS FORM 545 REV 11-99

Page 5

Bidder's Proposal
To
Engineer, Furnish, and Deliver Equipment,
Materials and Software
(Proposal shall be submitted in ink or typewritten)

To:
(HEREINAFTER CALLED THE "OWNER")

The undersigned (hereinafter called the "Bidder") hereby proposes to engineer, furnish,
and deliver the equipment, materials and software for each Project listed under Column 1,
"Project," in Article I, Section 1, and described in the plans, specifications and drawings
(hereinafter called the "Specifications") prepared by the Owner and attached hereto and made a
part hereof, financed by a loan to the Owner made or guaranteed by the United States of
America, acting through the Administrator of the Rural Utilities Service (hereinafter called the
"Administrator"), or by loans to the Owner by the United States of America and by the Rural
Telephone Bank, and designated
.

The Bidder has become informed as to the location and characteristics of the proposed
Project, has become informed as to the kind of facilities required before and during the delivery
and installation of the equipment, material, and software and has become acquainted with all
other matters that may affect the cost and time of delivery of the Project.
The Bidder agrees that if its bid is accepted the following terms and conditions shall
govern.
If, in submitting this proposal, the Bidder has taken any exception to the form of proposal
furnished by the Owner, the Bidder understands that the Owner and the Administrator may
evaluate the effect of such change as they see fit and they may exclude the proposal from
consideration in determining the award of the Contract.

RUS FORM 545 REV 11-99

ARTICLE I
Section 1. Bid Price. The Bidder will engineer, furnish, and deliver to the delivery points specified below the Equipment described in the Specifications for the
following sums:
(1)

(2)

(3)

(4)

(5)

(6)

(7)

(8)

Project
(See Notes 1, 2 and 3)

Base Bid

Delivery Point

Delivery
(See Note 4)

Completion of
The Project
(See Note 5)

Spare
Parts

Items

Maintenance
Tools

$

$

a

$

$

$

b

$

$

$

c

$

$

$

d

$

$

$

e

$

$

$

f

$

Totals

$

Total Base Bid

$

Alternate 1

$

$

g

$

Alternate 2

$

$

h

$

Alternate 3

$

$

i

$

Alternate 4

$

$

j

$

If a remote switching terminal, so designate and list after host office.
All items included in a Project shall have the same completion schedule.
Each Project shall be separated by a blank line.
Delivery time in calendar days.
Time in calendar days for Completion of the Project shall be no later than 90 days after the time established for Delivery.

Page 6

RUS FORM 545 REV 11-99

Note 1:
Note 2:
Note 3:
Note 4:
Note 5:

$
XXXXXXX
XXXXXXXXXXXXXXXXXXXXXXXXXXXXX $
XXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXX

Page 7

Section 2. Acceptable Equipment. Unless otherwise specified by the Owner (and with
advance written agreement by RUS), the Bidder agrees to furnish under this proposal only
equipment which is currently listed in RUS Information Publication 344-2 or covered by a letter
of technical acceptance issued by the Chairman, Technical Standards Committee "A"
(Telecommunications). The Bidder agrees also to furnish only materials, equipment, and
software which are new and of most recent issue and manufacture, as of the date of the bid
opening, or of near future release for which the Bidder can assure timely delivery.
Section 3. Changes in Project. The Owner, with the approval of the Administrator,
may from time to time prior to the delivery of equipment or software under this Contract effected
by the acceptance of this proposal, make reasonable changes, additions to or subtractions from
the Specifications which are part of the proposal as conditions may warrant. However, if
substantial changes in the Project shall require an extension of time, a reasonable extension will
be granted if the Bidder shall make a written request therefor to the Owner within thirty (30)
days after any such change is made. Further, if the cost to the Bidder shall be increased or
decreased by any such change or addition, the Contract price shall be increased or decreased by a
reasonable amount in accordance with a contract amendment signed by the Owner and the
Bidder and approved by the Administrator. No claim for additional compensation for any such
change or addition will be considered unless the Bidder shall have made a written request
therefor to the Owner prior to the commencement of work in connection with such change or
addition. The delivery times specified under Column 4, "Delivery", in Article I, Section 1, can
only be changed by a Contract amendment approved by the Bidder, the Owner and RUS.
Section 4. Taxes. The bid prices herein set forth do not include any amounts payable by
the Bidder or the Owner on account of taxes imposed by any taxing authority upon the sale,
purchase, or use of materials, supplies, equipment, or software to be incorporated in the
Project(s). If any such tax is applicable to the sale, purchase, or use of materials, supplies,
equipment, or software hereunder, the amount thereof shall be stated separately on all invoices
and paid by the Owner.

Article II
Delivery
Section 1. Time of Delivery. The time of delivery of materials, equipment, and
software is of the essence in this Contract. The Bidder shall deliver the materials, equipment, and
software required hereunder for each Project upon the time intervals established under Column
4, "Delivery," in Article I, Section 1, after the Administrator shall have approved this Contract in
writing. The times for such delivery shall be extended for the period of any reasonable delay due
exclusively to causes beyond the control and without the fault of the Bidder, including, but not
limited to, acts of God, fires, strikes, floods, changes in the Specifications as herein provided,
and acts or omissions of the Owner with respect to matters for which the Owner is solely
responsible. However, no such extension of time shall be granted the Bidder unless within thirty
(30) days after Bidder becomes aware of the happening of any event relied upon by the Bidder
for such an extension of time the Bidder shall have made a request therefor in writing to the
RUS FORM 545 REV 11-99

Page 8

Owner. Further, no delay in such time for delivery of materials, equipment, and software shall
result in any liability on the part of the Owner, except that the Owner shall be responsible for and
shall pay the Bidder on demand all additional, supportable costs, and expenses incurred by the
Bidder due to delays to the extent such delays are caused by the Owner's failure to perform its
obligations under this Contract unless the Owner's failure to perform is caused by forces beyond
its control.
Section 2. Sequence of Delivery. All Projects shall be delivered in the sequence in
which they are listed under Column 1, "Project," in Article I, Section 1.
Section 3. Inspection and Tests. All materials, equipment, and software used therein
shall be subject to the inspection, test, and approval of the Owner and Administrator, in
accordance with the Specifications. The Bidder shall furnish all pertinent information required
concerning the nature or source of materials. The Owner and the Administrator shall have the
right to inspect pertinent records (other than manufacturing cost information) of the Bidder and
of any subcontractor relevant to this Project(s). The Bidder shall provide all reasonable facilities
necessary for such inspection and tests, except that the Bidder is not required to provide test
equipment for the Owner's tests unless specifically required in the Specifications. Failure of the
Owner to make inspections shall not release the Bidder from performance required hereunder.
The Owner shall make inspections and tests of each Project for compliance with the
Specifications and provide the Bidder the results of such inspections and tests in writing. If the
Owner has not completed its inspections and tests and provided the Bidder the results within
sixty (60) days after the date of delivery as set forth under Column 4, "delivery" in Article I,
Section 1, the Owner shall (1) pay to the Bidder the costs incurred by the Bidder as a result of
this delay, and (2) grant an extension of time for the Completion of the Project equal to the
number of days from the date of the end of the sixty (60) day period until the date the Owner
provides such results to the Bidder. A longer period of time for inspection and tests can be
allowed if agreed to in writing by the Bidder and the Owner.
Within thirty (30) days of receipt of the results of the inspections and tests from the
Owner, the Bidder shall correct all deficiencies, if any, listed on the test results summary and
notify the Owner in writing of such corrections, at which time a final Owner's inspection and test
of each Project shall be conducted. If tests subsequent to this are made necessary by the Bidder's
failure to satisfactorily resolve all such deficiencies as previously listed, the Bidder shall pay the
Owner for the cost incurred by the Owner for all such subsequent tests.
Section 4. Defective Workmanship, Materials Equipment, or Software. Throughout
the warranty period defined below the Bidder shall, within thirty (30) days of written notice from
the Owner, and without charge to the Owner, at the Bidder's option, either remedy or replace any
materials, equipment, or software found to be defective in material, or workmanship, or not in
conformity with the Specification. This is subject to the following definitions and conditions:
(a) The warranty start date for a Project is the scheduled date of Completion of the
Project as set forth under Column 5, "Completion of the Project," in Article I, Section 1, or such
earlier date that such Project is certified complete. The warranty period is twelve (12) months

RUS FORM 545 REV 11-99

Page 9

from the warranty start date. If circumstances or events under the control of the Bidder cause a
delay beyond the scheduled date of Completion of the Project, the warranty period is twelve (12)
months from the actual date of Completion of the Project, as defined in Article VII, Section 1.
The warranty period shall not be extended due to delays caused by the Owner.
(b) Without regard to the expiration of the warranty period set forth above, the Bidder
warrants to the Owner that any Software furnished under this Contract shall function, for a
period of five (5) years from the warranty start date defined in subsection (a) above, in
accordance with the specifications and any written or printed technical material provided by the
Bidder to explain the operation of the Software and aid in its use. The Bidder shall correct all
deficiencies within thirty (30) days from the date of receipt by the Bidder of written notice of
such deficiencies from the Owner. An extension of this thirty (30) day period may be allowed
only if agreed upon by the Owner. It shall be the Bidder's obligation to insert and thoroughly
test, at no charge to the Owner, any software amendment or alteration provided to satisfy the
obligations of this Section 4. If a deficiency is detected or a correction made within the final
ninety (90) days of the warranty, the warranty shall be extended to a date ninety (90) days after
the deficiency has been corrected.
(c) The Owner shall pay the Bidder for any use of the Bidder's technical assistance
center except for usage to diagnose defects as provided in this Section 4.
(d) The warranty continues in full force and effect whether or not the Owner has
accepted the materials, equipment, or software, or by the issuing of any certificate with respect to
Completion of the Project.
(e) The warranty does not cover defects in materials, equipment, or software that are
caused by modifications to or abuse of materials, equipment, or software by the Owner or the
Owner's agents, including but not limited to, the Firm contracted by the Owner to install the
materials, equipment, and software.
(f) The Owner shall bear the cost and risk of shipping defective components to the
Bidder's designated repair center. The Bidder shall bear the cost and risk of shipping new or
repaired replacement components to the Owner.

Article III
Payments
Section 1. Payment of 90 Percent.
The Bidder shall provide the Owner with written estimates, including the prices, of the
materials, equipment, and software delivered to the site of each Project listed under column 2, in
Article I, Section 1. If the Owner approves these estimates, the Owner will pay the Bidder 90
percent of the estimates when all materials, equipment, and software required to put each Project
into operation have been delivered to the site of such Project.

RUS FORM 545 REV 11-99

Page 10

Section 2. Payment of Balance. Upon completion of installation (by others) of the
equipment, but prior to the payment to the Bidder of any amount in excess of ninety percent
(90%) of the Total Contract Price, the Owner shall make a final inspection of the materials,
equipment, and software provided hereunder as set forth under Article II, Section 3, Inspections
and Tests. If the materials, equipment, and software shall be found to be in accordance with the
Specifications and all provisions hereunder, the owner shall certify such fact to the Administrator
for approval and as to the amount of the balance found to be due to the bidder. When such
approval has been given, the Owner shall pay to the Bidder all unpaid amounts to which the
Bidder shall be entitled hereunder. However, such final payments shall be made not later than
one hundred twenty (120) days after delivery as set forth under Column 4, "Delivery" in Article
I, Section 1, unless approval by the Administrator shall be withheld or delayed due to Bidder's
actions or failure to act.
Section 3. Interest on Unpaid Amounts. Payment on undisputed invoices submitted by
the Bidder shall be due thirty (30) days after receipt. Any amounts of these invoices not paid
when due shall accrue interest at a rate one and one-half percent (1 1/2%) per year higher than
the "Prime Rate" published in the Wall Street Journal in its first issue of the month in which
payment becomes due and changing each subsequent month with the first issue published in the
respective month.
Section 4. Acceptance Not Waiver. Acceptance by the Owner of equipment, materials,
or software while the Bidder is in default under any provision of this Contract shall not be
construed as a waiver by the Owner of any right hereunder including, without limitation, any
right to liquidated damages the Owner may have by virtue of Article V, Section 2.

Article IV
Particular Undertakings of the Bidder
Section 1. Possession and Control. The equipment, materials, and software purchased
under this Contract, until such date or dates when the Owner may take possession and control,
shall be under the charge and control of the Bidder and during such period of control by the
Bidder all risks in connection therewith, and in connection with the equipment, materials, and
software to be used therein, shall be borne by the Bidder. The Bidder shall make good and fully
repair all damages to the equipment, materials, and software under the control of the Bidder by
reasons of any act of God, or any other casualty or cause whether or not the same shall have
occurred by reason of the Bidder's negligence.
Section 2. Termination of Bidder's Risks and Obligations. The Bidder shall deliver
to the Owner, and the Owner shall accept, full possession and control of each Project on the date
of delivery. Upon such delivery of possession and control of any Project the Bidder's risks and
obligations as set forth above pertaining to such Project shall be terminated; provided, however,
that nothing herein contained shall relieve the Bidder of its obligation for full performance under
the Specifications, or its liability with respect to defective materials, equipment, or software as

RUS FORM 545 REV 11-99

Page 11

specified in Article II, Section 4, hereof. The equipment shall not be installed until delivery of
possession and control to the Owner has been accomplished, as set forth above.
Section 3. Purchase of Materials. The Bidder shall purchase all materials and supplies
except software outright and not subject to any conditional sales agreements, bailment lease or
other agreement reserving unto the seller any right, title, or interest therein. Materials and
supplies other than software shall become the property of the Owner as the Owner makes
payments therefor to the Bidder in accordance with Article III, Section 1(a).
Section 4. Software License. If the Bidder requires a software license agreement
covering the rights, terms, and conditions of the use and assignability of all software integral to
the operation of the Project, the license shall be in the form of Addendum 1 to this Contract (See
7 CFR 1753.38(c)).
Section 5. Assignment of Guarantees. All guarantees of materials, equipment,
workmanship, and software running in favor of the Bidder shall be transferred and assigned to
the Owner upon Completion of the Project and at such time as the Bidder receives final payment.
Any such guarantees shall be in addition to the Bidder's warranty defined in Article II, Section 4.
This provision may be modified with respect to a particular warranty if the Bidder demonstrates
to the satisfaction of RUS and the Owner that a transfer is not possible.
Section 6. Patent, Copyright, Trademark, and Trade Secret Infringement. The
Bidder shall hold harmless and indemnify the Owner from any and all claims, suits, and
proceedings for the infringement of any patent, copyright, trademark, or violation of trade secrets
covering any equipment or software used in the work, except for items of the Owner's design or
selection. If the Owner's use of equipment or software is enjoined, the Bidder shall promptly, at
its own expense, modify or replace the infringing equipment or software so that it no longer
infringes but remains functionally equivalent, or obtain for the Owner a license or other right to
use the equipment or software. This shall be in addition to any other rights or claims, which the
Owner may have. The Bidder shall, at its own expense, (and the Owner agrees to permit Bidder
to do so,) defend any suits which may be instituted by any party against the Owner for alleged
infringement of patents, copyright, trademark, or violation of trade secrets relative to the Bidder's
performance hereunder. Either party shall notify the other promptly of any such claims, and the
Owner shall give to the Bidder full authority and opportunity to settle such claims, and shall
reasonably cooperate with the Bidder in obtaining information relative to such claims.
Section 7. Compliance with Statutes and Regulations. The Bidder shall comply with
all applicable laws, statutes, ordinances, rules, and regulations. The Bidder acknowledges that it
is familiar with the Rural Electrification Act of 1936, as amended (7 U.S.C. 901 et seq.), the
Anti-Kickback Acts, as amended (40 U.S.C. 276c; 41 U.S.C. 51 et seq.), and any rules and
regulations issued pursuant thereto, and 18 U.S.C. 201, 286, 287, 641, 666, 874, 1001, 1361 and
1366, as amended.
The Bidder represents that to the extent required by Executive Orders 12549 (3 CFR,
1985-1988 Comp., p. 189) and 12689 (3 CFR, 1989 Comp., p. 235), Debarment and Suspension,
and 7 CFR part 3017, it has submitted to the Owner a duly executed certification in the form

RUS FORM 545 REV 11-99

Page 12

prescribed in 7 CFR part 3017.
The Bidder represents that, to the extent required, it has complied with the requirements
of Pub. L. 101-121, Section 319, 103 Stat. 701, 750-765 (31 U.S.C. 1352), entitled "Limitation
on use of appropriated funds to influence certain Federal contracting and financial transactions,"
and any rules and regulations issued pursuant thereto.
Article V
Remedies
Section 1. Completion on Bidder's Default. If default shall be made by the Bidder in
the material, equipment, or software furnished hereunder, the Owner, without in any manner
limiting its legal and equitable remedies in the circumstances, may serve upon the Bidder a
written notice requiring the Bidder to cause such default to be corrected forthwith. Unless within
thirty (30) days after the service of such notice upon the Bidder such default shall be corrected or
arrangements for the correction thereof, satisfactory to both the Owner and the Administrator,
shall have been made by the Bidder, the Owner may take over the performance of the Bidder's
obligations hereunder and prosecute the same to completion by contract or otherwise for the
account and at the expense of the Bidder, and the Bidder shall be liable to the Owner for any
supportable cost or expense in excess of the bid price occasioned thereby. The Owner, in such
contingency, may exercise any rights, claims, or demands which the Bidder may have against
third persons in connection herewith and for such purpose the Bidder does hereby assign,
transfer, and set over unto the Owner all such rights, claims, and demands.
Section 2. Liquidated Damages. Should the Bidder fail to complete any Project as
shown under Column 5, "Completion of the Project," in Article I, Section 1, due to
circumstances or events under control of the Bidder, within the time herein agreed upon, after
giving effect to extensions of time, if any, herein provided, then, in that event and in view of the
difficulty of estimating with exactness damages caused by such delay, the Owner shall, so long
as the subject Project shall not have been placed in service, have the right to deduct from and
retain out of such moneys which may be then due, or which may become due and payable to the
Bidder, the sum of:
dollars ($

for

dollars ($

for

(Project)
(Project)
dollars ($

for
(Project)

per day for each and every day that such completion is delayed beyond the scheduled time for
Completion of the Project, as liquidated damages and not as a penalty, up to the amount of the
respective Base Bid plus accepted alternates for the affected Project; provided, however, that the
Owner shall promptly notify the Bidder in writing of the manner in which the amount claimed as
liquidated damages was computed. The Bidder shall pay to the Owner the amount necessary to

RUS FORM 545 REV 11-99

Page 13

effect such payment in full. Such payment is not to be reduced by the value of any partial
performance by the Bidder.
At the technical sessions, each Bidder shall identify all features and capabilities that are
not fully developed or do not have a verifiable satisfactory field performance record. If the
Owner allows these features to be bid as separate Projects, then they are to be individually listed
under Columns 1 through 8, in Article I, Section 1. These unproven features and capabilities are
to be individually listed in this Section 2 also, with liquidated damages amounts determined by
the Owner and stated for each. If a Bidder neglects to identify any such feature at the technical
session, delay in providing the feature is considered a delay in completing the associated Project
and the Owner may assess liquidated damages listed for that Project regardless of whether the
Project is placed in service.
Section 3. Consequential Damages. In no event shall the Bidder's liability for
incidental or consequential loss or damage, except for personal injury or tangible property
damage, exceed the amount of 10 times the total contract price, as amended.
Section 4. Enforcement of Remedies by Administrator. The Administrator may on
behalf of the Owner exercise any right or enforce any remedy, which the Owner may exercise or
enforce hereunder.
Section 5. Cumulative Remedies. Every right or remedy herein conferred upon or
reserved to the Owner or the Administrator shall be cumulative and shall be in addition to every
right and remedy now or hereafter existing at law or in equity or by statute and the pursuit of any
right or remedy shall not be construed as an election; provided, however, that the provisions of
Section 2 of this Article V shall be the exclusive measure of damages for failure by the Bidder to
have effected the Completion of Project within the time herein agreed upon.

Article VI
Equal Employment
Section 1. The Bidder.
(a) The Bidder represents that:
(1) It has
it has, that
(2) It has

RUS FORM 545 REV 11-99

, does not have
, has not

, 100 or more employees, and if

, furnished the Equal Employment

Page 14

Opportunity Employers Information Report EEO-1, Standard Form 100, required of employers
with 100 or more employees pursuant to Executive Order 11246, as amended, and Title VII of
the Civil Rights Act of 1964.
(b) The Bidder agrees that it will obtain, prior to the award of any subcontract for more
than $10,000 hereunder to a subcontractor with 100 or more employees, a statement, signed by
the proposed subcontractor, that the proposed subcontractor has filed a current report on
Standard Form 100.
(c) The Bidder agrees that if it has 100 or more employees and has not submitted a report
on Standard Form 100 for the current reporting year and that if this contract will amount to more
than $10,000, the Bidder will file such report, as required by law, and notify the Owner in
writing of such filing prior to the Owner's acceptance of this proposal.
(d) The Bidder certifies that it does not maintain or provide for its employees any
segregated facilities at any of its establishments, and that it does not permit its employees to
perform their services at any location, under its control, where segregated facilities are
maintained. The Bidder certifies further that it will not maintain or provide for its employees any
segregated facilities at any of its establishments, and that it will not permit its employees to
perform their services at any location, under its control, where segregated facilities are
maintained. The Bidder agrees that a breach of this certification is a violation of the Equal
Opportunity Clause in this contract. As used in this certification, the term "segregated facilities"
means any waiting rooms, work areas, restrooms and washrooms, restaurants and other eating
areas, timeclocks, locker rooms and other storage or dressing areas, parking lots, drinking
fountains, recreation or entertainment areas, transportation, and housing facilities provided for
employees which are segregated by explicit directive or are in fact segregated on the basis of
race, color, religion, or national origin, because of habit, local custom, or otherwise. The Bidder
agrees that (except where it has obtained identical certifications from proposed subcontractors
for specific time periods) it will obtain identical certifications from proposed subcontractors
prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions
of the Equal Opportunity Clause, and that it will retain such certifications in its files.
Section 2. During the performance of this contract, the Contractor agrees as
follows:
(a) The Contractor will not discriminate against any employee or applicant for
employment because of race, color, religion, sex, or national origin. The Contractor will take
affirmative action to ensure that applicants are employed, and that employees are treated during
employment without regard to their race, color, religion, sex, or national origin. Such action shall
include, but not be limited to, the following: employment, upgrading, demotion or transfer;
recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of
compensation; and selection for training, including apprenticeship. The Contractor agrees to post
in conspicuous places available to employees and applicants for employment, notices to be
provided setting forth the provisions of this nondiscrimination clause.
(b) The Contractor will, in all solicitations or advertisements for employees placed by or

RUS FORM 545 REV 11-99

Page 15

on behalf of the Contractor, state that all qualified applicants shall receive consideration for
employment without regard to race, color, religion, sex, or national origin.
(c) The Contractor will send to each labor union or representative of workers with which
the Bidder has a collective bargaining agreement or other contract or understanding, a notice to
be provided advising the said labor union or workers' representative of the Contractor's
commitments under this section, and shall post copies of the notice in conspicuous places
available to employees and applicants for employment.
(d) The Contractor will comply with all provisions of Executive Order 11246 and of the
rules, regulations, and relevant orders of the Secretary of Labor.
(e) The Contractor will furnish all information and reports required by Executive Order
11246 and by rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and
will permit access to the Contractor's books, records, and accounts by the administering agency
and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules,
regulations, and orders.
(f) In the event of the Contractor's noncompliance with the nondiscrimination clauses of
this contract or with any of the said rules, regulations, or orders, this contract may be canceled,
terminated, or suspended in whole or in part and the Contractor may be declared ineligible for
further Government contracts or federally assisted construction contracts in accordance with
procedures authorized in Executive Order 11246 and such other sanctions as may be imposed
and remedies invoked as provided in the said Executive Order 11246 or by rule, regulation or
order of the Secretary of Labor, or as otherwise provided by law.
(g) The Contractor will include the portion of the sentence immediately preceding
paragraph (a) and the provisions of paragraphs (a) through (g) in every subcontract or purchase
order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant
to Section 204 of Executive Order 11246 so that such provisions will be binding upon each
subcontractor or vendor. The Contractor will take such action with respect to any subcontract or
purchase order as the administering agency may direct as a means of enforcing such provisions,
including actions for noncompliance; provided, however, that in the event a contractor becomes
involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such
direction by the administering agency, the Contractor may request the United States to enter into
such litigation to protect the interests of the United States.
Section 3. Equal Employment Opportunity Specifications.
(a) As used in these specifications:
"Covered area" means the geographical area described in the solicitation from which this
contract resulted;
"Director" means Director, Office of Federal Contract Compliance Programs, United
States Department of Labor, or any person to whom the Director delegates authority;

RUS FORM 545 REV 11-99

Page 16

"Employer identification number" means the Federal Social Security number used on the
Employer's Quarterly Federal Tax Return, U.S. Treasury Department Form 941; and
"Minority" includes:
(i) Black (all persons having origins in any of the Black African racial groups not of
Hispanic origin);
(ii) Hispanic (all persons of Mexican, Puerto Rican, Cuban, Central or South American
or other Spanish Culture or origin, regardless of race);
(iii) Asian and Pacific Islander (all persons having origins in any of the original peoples
of the Far East, Southeast Asia, the Indian Subcontinent, or the Pacific Islands); and
(iv) American Indian or Alaskan Native (all persons having origins in any of the original
peoples of North America and maintaining identifiable tribal affiliations through membership
and participation or community identification).
(b) Whenever the Contractor, or any subcontractor at any tier, subcontracts a portion of
the work involving any construction trade, it shall physically include in each subcontract in
excess of $10,000 the provisions of these specifications and the Notice which contains the
applicable goals for minority and female participation and which is set forth in the solicitations
from which this contract resulted.
(c) If the Contractor is participating (pursuant to 41 CFR 60-4.5) in a Hometown Plan
approved by the U.S. Department of Labor in the covered area either individually or through an
association, its affirmative action obligations on all work in the Plan area (including goals and
timetables) shall be in accordance with that Plan for those trades which have unions participating
in the Plan. Contractors must be able to demonstrate their participation in and compliance with
the provisions of any such Hometown Plan. Each Contractor or Subcontractor participating in an
approved Plan is individually required to comply with its obligations under the EEO clause, and
to make a good faith effort to achieve each goal under the Plan in each trade in which it has
employees. The overall good faith performance by other contractors or subcontractors toward a
goal in an approved Plan does not excuse any covered contractor's or subcontractor's failure to
take good faith efforts to achieve the Plan goals and timetables.
(d) The Contractor shall implement the specific affirmative action standards provided in
paragraphs (g) (i) through (xvi) of these specifications. The goals set forth in the solicitation
from which this contract resulted are expressed as percentages of the total hours of employment
and training of minority and female utilization the Contractor should reasonably be able to
achieve in each construction trade in which it has employees in the covered area. Covered
construction contractors performing construction work in geographical areas where they do not
have a federal or federally assisted construction contract shall apply the minority and female
goals established for the geographical area where the work is being performed. Goals are
published periodically in the Federal Register in notice form, and such notices may be obtained

RUS FORM 545 REV 11-99

Page 17

from any Office of Federal Contract Compliance Programs office or from Federal procurement
contracting officers. The Contractor is expected to make substantially uniform progress in
meeting its goals in each craft during the period specified.
(e) Neither the provisions of any collective bargaining agreement, nor the failure by a
union with which the Contractor has a collective bargaining agreement, to refer either minorities
or women shall excuse the Contractor's obligations under these specifications, Executive Order
11246 or the regulations promulgated pursuant thereto.
(f) In order for the nonworking training hours of apprentices and trainees to be counted
in meeting the goals, such apprentices and trainees must be employed by the Contractor during
the training period, and the Contractor must have made a commitment to employ the apprentices
and trainees at the completion of their training, subject to the availability of employment
opportunities. Trainees must be trained pursuant to training programs approved by the U.S.
Department of Labor.
(g) The Contractor shall take specific affirmative actions to ensure equal employment
opportunity. The evaluation of the Contractor's compliance with these specifications shall be
based upon its effort to achieve maximum results from its actions. The Contractor shall
document these efforts fully, and shall implement affirmative action steps at least as extensive as
the following:
(i) Ensure and maintain a working environment free of harassment, intimidation, and
coercion at all sites, and in all facilities at which the Contractor's employees are assigned to
work. The Contractor, where possible, will assign two or more women to each construction
project. The Contractor shall specifically ensure that all foremen, superintendents, and other onsite supervisory personnel are aware of and carry out the Contractor's obligation to maintain such
a working environment, with specific attention to minority or female individuals working at such
sites or in such facilities.
(ii) Establish and maintain a current list of minority and female recruitment sources,
provide written notification to minority and female recruitment sources and to community
organizations when the Contractor or its unions have employment opportunities available, and
maintain a record of the organizations' responses.
(iii) Maintain a current file of the names, addresses and telephone numbers of each
minority and female off-the-street applicant and minority or female referral from a union, a
recruitment source or community organization and of what action was taken with respect to each
such individual. If such individual was sent to the union hiring hall for referral and was not
referred back to the Contractor by the union or, if referred, not employed by the Contractor, this
shall be documented in the file with the reason therefore, along with whatever additional actions
the Contractor may have taken.
(iv) Provide immediate written notification to the Director when the union or unions
with which the Contractor has a collective bargaining agreement has not referred to the
Contractor a minority person or woman sent by the Contractor, or when the Contractor has other

RUS FORM 545 REV 11-99

Page 18

information that the union referral process has impeded the Contractor's efforts to meet its
obligations.
(v) Develop on-the-job training opportunities and/or participate in training programs for
the area which expressly include minorities and women, including upgrading programs and
apprenticeship and trainee programs relevant to the Contractor's employment needs, especially
those programs funded or approved by the Department of Labor. The Contractor shall provide
notice of these programs to the sources compiled under (g)(ii) above.
(vi) Disseminate the Contractor's EEO policy by providing notice of the policy to unions
and training programs and requesting their cooperation in assisting the Contractor in meeting its
EEO obligations; by including it in any policy manual and collective bargaining agreement; by
publicizing it in the company newspaper, annual report, etc.; by specific review of the policy
with all management personnel and with all minority and female employees at least once a year;
and by posting the company EEO policy on bulletin boards accessible to all employees at each
location where construction work is performed.
(vii) Review, at least annually, the company's EEO policy and affirmative action
obligations under these specifications with all employees having any responsibility for hiring,
assignment, layoff, termination, or other employment decisions including specific review of
these items with onsite supervisory personnel such as Superintendents, General Foremen, etc.,
prior to the initiation of construction work at any job site. A written record shall be made and
maintained identifying the time and place of these meetings, persons attending, subject matter
discussed, and disposition of the subject matter.
(viii) Disseminate the Contractor's EEO policy externally by including it in any
advertising in the news media, specifically including minority and female news media, and
providing written notification to and discussing the Contractor's EEO policy with other
contractors and subcontractors with whom the Contractor does or anticipates doing business.
(ix) Direct its recruitment efforts, both oral and written, to minority, female, and
community organizations, to schools with minority and female students and to minority and
female recruitment and training organizations serving the Contractor's recruitment area and
employment needs. Not later than one month prior to the date for the acceptance of applications
for apprenticeship or other training by any recruitment source, the Contractor shall send written
notification to organizations such as the above, describing the openings, screening procedures,
and tests to be used in the selection process.
(x) Encourage present minority and female employees to recruit other minority persons
and women and, where reasonable, provide after school, summer, and vacation employment to
minority and female youth both on the site and in other areas of a Contractor's work force.
(xi) Validate all tests and other selection requirements where there is an obligation to do
so under 41 CFR Part 60-3.
(xii) Conduct, at least annually, an inventory and evaluation at least of all minority and

RUS FORM 545 REV 11-99

Page 19

female personnel for promotional opportunities and encourage these employees to seek or to
prepare for, through appropriate training, etc., such opportunities. (xiii) Ensure that seniority
practices, job classifications, work assignments and other personnel practices, do not have a
discriminatory effect by continually monitoring all personnel and employment related activities
to ensure that the EEO policy and the Contractor's obligations under these specifications are
being carried out.
(xiv) Ensure that all facilities and company activities are nonsegregated except that
separate or single-user toilet and necessary changing facilities shall be provided to assure privacy
between the sexes.
(xv) Document and maintain a record of all solicitations of offers for subcontracts from
minority and female construction contractors and suppliers, including circulation of solicitations
to minority and female contractor associations and other business associations.
(xvi) Conduct a review, at least annually, of all supervisors' adherence to and
performance under the Contractor's EEO policies and affirmative action obligations.
(h) Contractors are encouraged to participate in voluntary associations, which assist in
fulfilling one or more of their affirmative action obligations (g)(i) through (xvi). The efforts of a
contractor association, joint contractor-union, contractor-community, or other similar group of
which the Contractor is a member and participant, may be asserted as fulfilling any one or more
of its obligations under (g)(i) through (xvi) of these specifications provided that the Contractor
actively participates in the group, makes every effort to assure that the group has a positive
impact on the employment of minorities and women in the industry, ensures that the concrete
benefits of the program are reflected in the Contractor's minority and female workforce
participation, makes a good faith effort to meet its individual goals and timetables, and can
provide access to documentation which demonstrates the effectiveness of actions taken on behalf
of the Contractor. The obligation to comply, however, is the Contractor's and failure of such a
group to fulfill an obligation shall not be a defense for the Contractor's noncompliance.
(i) A single goal for minorities and a separate single goal for women have been
established. The Contractor, however, is required to provide equal employment opportunity and
to take affirmative action for all minority groups, both male and female, and all women, both
minority and non-minority. Consequently, the Contractor may be in violation of Executive Order
if a particular group is employed in a substantially disparate manner (for example, even though
the Contractor has achieved its goals for women generally, the Contractor may be in violation of
Executive Order 11246 if a specific minority group of women is underutilized).
(j) The Contractor shall not use the goals and timetables or affirmative action standards
to discriminate against any person because of race, color, religion, sex, or national origin.
(k) The Contractor shall not enter into any subcontract with any person or firm debarred
from Government contracts pursuant to Executive Order 11246.
(l) The Contractor shall carry out such sanctions and penalties for violation of these

RUS FORM 545 REV 11-99

Page 20

specifications and of the Equal Opportunity Clause, including suspension, termination, and
cancellation of existing subcontracts as may be imposed or ordered pursuant to Executive Order
11246 and its implementing regulations, by the Office of Federal Contract Compliance
Programs. Any Contractor who fails to carry out such sanctions and penalties shall be in
violation of these specifications and Executive Order 11246.
(m) The Contractor, in fulfilling its obligations under these specifications, shall
implement specific affirmative action steps, at least as extensive as those standards prescribed in
paragraph (g) of these specifications, so as to achieve maximum results from its efforts to ensure
equal employment opportunity. If the Contractor fails to comply with the requirements of
Executive Order 11246, as amended, the implementing regulations, or these specifications, the
Director shall proceed in accordance with 41 CFR 60-4.8.
(n) The Contractor shall designate a responsible official to monitor all employment
related activity to ensure that the company EEO policy is being carried out, to submit reports
relating to the provisions hereof as may be required by the Government and to keep records.
Records shall at least include for each employee the name, address, telephone numbers,
construction trade, union affiliation if any, employee identification number when assigned, social
security number, race, sex, status (e.g., mechanic, apprentice, trainee, helper, or laborer), dates of
changes in status, hours worked per week in the indicated trade, rate of pay, and locations at
which the work was performed. Records shall be maintained in an easily understandable and
retrievable form; however, to the degree that existing records satisfy this requirement,
contractors shall not be required to maintain separate records.
(o) Nothing herein provided shall be construed as a limitation upon the application of
other laws which establish different standards of compliance or upon the application of
requirements for the hiring of local or other area residents (e.g. those under the Public Works
Employment Act of 1977 and the Community Development Block Grant Program).
Section 4. In this Article VI.
(a) The term "Contractor" shall also mean "Bidder" or "Subcontractor" as applicable.
(b) The provisions of Sections 2 & 3 are applicable to the extent required by law. In
determining whether these sections are applicable, reference should be made to Office of Federal
Contract Compliance Programs regulations (41 CFR Part 60).

RUS FORM 545 REV 11-99

Page 21

Article VII
Miscellaneous
Section 1. Definitions.
The term "Completion of the Contract" shall mean accomplishment of completion of the
Project for all central offices (and associated remote switching terminals), features and services
listed under Column 1, "Project," in Article I, Section 1, and all alternates accepted by the
Owner, on the Owner's acceptance.
The term "Completion of the Project" shall mean full performance by the Bidder of the
Bidder's obligations herein set out and all amendments and revisions thereof for a central office
(and all associated remote switching terminals), feature or service. The scheduled date for
completion of the Project is ninety (90) days after delivery as specified under Column 4,
"Delivery," in Article I, Section 1, as amended or adjusted under Article II, Section 1, and
Section 3. The scheduled date for Completion of the Project is the date from which liquidated
damages are computed. The actual date of completion of the Project shall be the date of the
receipt by the Owner from the Bidder of written notification that all deficiencies listed on the
results of acceptance tests have been corrected; provided, that the final inspection and tests by
the Owner finds the deficiencies satisfactorily resolved. If the deficiencies have not been
satisfactorily resolved, the actual date of completion of the Project shall be the date that the
deficiencies are fully and satisfactorily resolved as determined by subsequent Owner's tests. The
Certificate of Completion approved and signed by the Owner and approved in writing by the
Administrator shall be conclusive evidence as to the fact of Completion of the Project and the
date thereof. Full compliance with the procedure for ``Completion of the Project'' and an
individual Certificate of Completion is required for each Project listed under Column 1,
``Project,'' in Article I, Section 1.
The "Contract" shall consist of the Notice and Instructions to Bidders, the Bidder's
proposal and the Owner's acceptance, and the Specifications.
The term "days" shall mean calendar days.
The term "minor errors or irregularities" shall mean a defect or variation in a Bidder's bid
that is a matter of form and not of substance. Errors or irregularities are ``minor'' if they can be
corrected or waived without being prejudicial to other Bidders and when they do not affect the
price, quantity, quality, or timeliness of construction. Unless otherwise noted, the Owner
determines whether an error or irregularity is ``minor.''
The term "placed in service" shall mean used by the Owner to earn revenue.
The term "Project" shall mean a central office and all associated remote switching
terminals (if any), a remote switching terminal if purchased without a supporting central office, a
feature (or group of features), or a service (or group of services), which is listed under Column 1,
``Project,'' in Article I, Section 1. The only instance in which a remote switching terminal can

RUS FORM 545 REV 11-99

Page 22

constitute a separate Project is where such remote switching terminal is purchased with
associated modifications to its supporting host switch but no other modifications to the host
switch are specified. A Project will have a single completion schedule listed under Column 5
``Completion of the Project,'' in Article I, Section 1, and a single liquidated damages amount
shown in Article V, Section 2. The Contract may consist of one or more Projects.
The term "Software" shall mean computer programs contained on a tape, disc,
semiconductor device or other memory device or system memory consisting of logic instructions
and instruction sequences in machine-readable object code, which manipulate data in the central
processor, control and perform input/output operations, perform error diagnostic and recovery
routines, control call processing, and perform peripheral control, and administrative and
maintenance functions; as well as associated documentation, excluding source code, used to
describe, maintain, and use the programs provided under the Contract.
The term "Specifications" shall mean the minimum performance requirements of the
Owner as contained in the documents listed below, and attached to this agreement:
RUS Form
RUS Form
RUS Form
RUS Form

, dated
, dated
, dated
, dated

Requirements may have been amended by specific written exceptions in the Bidder's proposal
which have been agreed to by the Owner and accepted by the Administrator.
Section 2. Continuing Equipment Support--Parts, Service, and Software. In addition
to warranty repairs and replacement, the Bidder shall offer repair service and repair parts to the
Owner in accordance with the Bidder's practices and terms then in effect, for the Bidder's
manufactured equipment furnished pursuant to this Agreement. Such repair service or repair
parts shall be available for as long as the Bidder is manufacturing or stocking such equipment, or
for no less than eight (8) years after the Bidder has ceased manufacturing or offering such
equipment for sale. The Bidder shall also offer software support services to the Owner in
accordance with the Bidder's practices, terms, and charges then in effect, but in any event for no
less than five (5) years after the Bidder has ceased manufacturing or offering for sale such
software.
Section 3. Materials and Supplies. The Bidder shall use only such unmanufactured
articles, materials, and supplies as have been mined or produced in the United States, or in any
eligible country, and only such manufactured articles, materials, and supplies as have been
manufactured in the United States, or in any eligible country, substantially all from articles,
materials, or supplies mined, produced or manufactured, as the case may be, in the United States,
or in any eligible country, provided that other articles, materials, or supplies may be used in the
event and to the extent that the Administrator shall expressly authorize in writing such use
pursuant to the provisions of the Rural Electrification Act of 1938, being Title IV of Public
Resolution No. 122, 75th Congress, approved June 21, 1938. For purposes of this section, an
"eligible country" is any country that applies with respect to the United States an agreement

RUS FORM 545 REV 11-99

Page 23

ensuring reciprocal access for United States products and services and United States suppliers to
the markets of that country, as determined by the United States Trade Representative. The
Bidder agrees to submit to the Owner such certificate or certificates, signed by the Bidder and all
subcontractors, with respect to compliance with the foregoing provision as the Administrator
from time to time may require.
Section 4. Confidentiality. All information supplied by the Bidder to the Owner which
bears a legend or notice restricting its use, copying, or dissemination, except insofar as it may be
in the public domain through no acts attributable to the Owner, shall be treated by the Owner as
confidential information, and the Owner shall not reproduce any such information except for its
own internal use and as authorized by this Contract, and shall use any information only for
archival backup, in-house training, operating, maintenance, and administrative purposes and in
conjunction with its use of the equipment, materials, and software furnished hereunder. All
information supplied to the Bidder by the Owner which bears a legend or notice restricting its
use, copying, or dissemination, except insofar as it may be in the public domain through no acts
attributable to the Bidder, shall be treated by the Bidder as confidential information, and shall
not be used by the Bidder for any purpose adverse to the interests of the Owner, and shall not be
reproduced or distributed by the Bidder except for the Bidder's use in its performance under this
Contract. The foregoing confidentiality obligations do not apply to information which is
independently developed by the receiving party or which is lawfully received by the receiving
party free of restriction from another source having a right to so furnish such information, or is
already known to the receiving party at the time of disclosure free of restriction. If the Bidder has
failed to provide continuing equipment support as described in Article VII, Section 2, the Owner
is released from this obligation. This provision does not restrict release of information by the
United States of America pursuant to the Freedom of Information Act or other legal process.
Section 5. Entire Agreement. The terms and conditions of this Contract as approved by
RUS supersede all prior oral or written understandings between the parties. There are no
understandings or representations, expressed or implied, not expressly set forth herein.
Section 6. Survival of Obligations. The rights and obligations of the parties, which by
their nature, would continue beyond the termination, cancellation, or expiration of this Contract,
shall survive such termination or expiration.
Section 7. Non-Waiver. No waiver of any terms or conditions of this Contract, or the
failure of either party to enforce strictly any such term or condition on one or more occasions,
shall be construed as a waiver of the same or of any other terms or conditions of this Contract on
any other occasion.
Section 8. Releases Void. Neither party shall require releases or waivers of any
personal rights from representatives or employees of the other in connection with visits to its
premises, nor shall such parties plead such releases or waivers in any action or proceeding.
Section 9. Nonassignment of Contract. The Bidder shall not assign the Contract,
effected by acceptance of this proposal, or any part hereof, or enter into any contract with any
person, firm or corporation, for the performance of the Bidder's obligations hereunder, or any

RUS FORM 545 REV 11-99

Page 24

part hereof, without the approval in writing of the Owner and the Administrator.
Section 10. Choice of Law. The rights and obligations of the parties and all
interpretations and performance of this Contract shall be governed in all respects by the laws of
the State of
except for its rules with respect to the conflict of laws.
Section 11. Approval of the Administrator. The acceptance of this proposal by the
Owner shall not create a contract unless such acceptance shall be approved in writing by the
Administrator within ninety (90) days after the date hereof:
By
(Signature of Bidder)

(Name – Type or Print)

(Title)

(Company Name of Bidder)

(Address of Bidder)
Attest:

Secretary)

(Date)
The proposal must be signed with the full name of the Bidder. In the case of a
partnership, the proposal must be signed in the firm name by each partner. In the case of a
corporation, the proposal must be signed in the corporate name by a duly authorized officer and
the Corporate seal affixed and attested by the Secretary of the Corporation.
(If executed by other than the President, a Vice-President, the partners or the individual owner, a
power of attorney or other legally acceptable document authorizing execution shall accompany
this contract, unless such power of attorney is on file with RUS.)

RUS FORM 545 REV 11-99

Page 25

Acceptance
Subject to the approval of the Administrator, the Owner hereby accepts the proposal of

for the Project(s) herein described for the Total Base Bid of
$
and
Alternate For
Spare Parts, Item(s)

$

Maintenance Tools, Item(s).......... $
Alternate No. 1 add (deduct)......... $
Alternate No. 2 add (deduct)......... $
Alternate No. 3 add (deduct)......... $
Alternate No. 4 add (deduct)......... $
Alternate No. 5 add (deduct)......... $
Alternate No. 6 add (deduct)......... $
The total contract price is.... $
By
Owner

President
Attest:

Secretary

Date Of Acceptance

RUS FORM 545 REV 11-99