91071-ORCF Escrow Agreement for Off-site Facilities

Comprehensive Listing of Transactional Documents for Mortgagors, Mortgagees and Contractors

91071_orcf_Final_Clean

Transactional Documents for Mortgagees and Contractors

OMB: 2502-0605

Document [docx]
Download: docx | pdf


Escrow Agreement for Off-site Facilities

Section 232

U.S. Department of Housing
and Urban Development

Office of Residential

Care Facilities

OMB Approval No. 2502-0605

(Exp. 03/31/2018)


Public reporting burden for this collection of information is estimated to average 0.5 hours. This includes the time for collecting, reviewing, and reporting the data. The information is being collected to obtain the supportive documentation which must be submitted to HUD for approval and is necessary to ensure that viable projects are developed and maintained. The Department will use this information to determine if properties meet HUD requirements with respect to development, operation and/or asset management, as well as ensuring the continued marketability of the properties. This agency may not collect this information, and you are not required to complete this form unless it displays a currently valid OMB control number. 


Warning: Any person who knowingly presents a false, fictitious, or fraudulent statement or claim in a matter within the jurisdiction of the U.S. Department of Housing and Urban Development is subject to criminal penalties, civil liability, and administrative sanctions. 


This ESCROW AGREEMENT FOR OFF-SITE FACILITIES (“Agreement”) made this

      day of      , 20     , by and between      , (“Lender”), whose principal

address is      , and      , (“Borrower”), whose principal address is      , [and if

applicable,       (“Depository Institution”), whose principal address is      ], in connection with HUD Project No.      , located in the City/County of      , State of      , which Project will be
constructed from the proceeds of a Loan insured by HUD and made by Lender. (The definition of any capitalized term or word used herein can be found in this Agreement, the Regulatory Agreement between Borrower and HUD, the Note, and/or the Security Instrument, except that the term
“Program Obligations” means (1) all applicable statutes and any regulations issued by the Secretary pursuant thereto that apply to the Project, including all amendments to such statutes and regulations, as they become effective, except that changes subject to notice and comment rulemaking shall become effective only upon completion of the rulemaking process, and (2) all current requirements in HUD handbooks and guides, notices, and mortgagee letters that apply to the Project, and all future updates, changes and amendments thereto, as they become effective, except that changes subject to notice and comment rulemaking shall become effective only upon completion of the rulemaking process, and provided that such future updates, changes and amendments shall be applicable to the Project only to the extent that they interpret, clarify and implement terms in this Agreement rather than add or delete provisions from such document. Handbooks, guides, notices, and mortgagee letters are available on HUD's official website: (http://www.hud.gov/offices/adm/hudclips/index.cfm or a successor location to that site).)


RECITALS:

  1. HUD has issued a Firm Commitment to insure said Loan pursuant to the National Housing Act, as amended, and Program Obligations, on which mortgage insurance Borrower is relying for financing of the Project.


  1. It is necessary, in connection with the construction of the Project, to provide certain facilities lying outside of the property lines of the Land on which the Project is located, as set forth in the drawings and specifications for the off-site work dated       “Drawings and Specifications”), and supporting description and cost estimate, which supporting description and cost estimate are attached hereto as Exhibit “A”, and along with the Drawings and Specifications are made part of this Agreement (“Off-site Construction”).


  1. The Firm Commitment is conditioned upon the satisfactory assurance from Borrower that sufficient funds are available for the completion of Off-site Construction as indicated below.


  1. As used herein, the term “Completion Date” shall mean the date of      , 20     .




AGREEMENTS:


In consideration of the mutual promises and undertakings contained herein, and for the purpose of inducing the Lender to make and HUD to insure said Loan, the parties acknowledge and agree as follows:


  1. At or before initial endorsement of the Note by HUD for mortgage insurance, Borrower shall deposit, or cause to be deposited, with Lender or subject to the control and order of Lender with a depository institution satisfactory to Lender in accordance with Program Obligations, the sum of $      (“Escrow”).


  1. It is agreed that the Lender at all times shall control the Escrow. The Escrow shall take the form of [specify as applicable]:

cash, and/or

(if permitted by Program Obligations) one or more unconditional, irrevocable letter(s) of credit issued to Lender by a banking institution, attached hereto as Exhibit “B”. The rating of the issuing banking institution and the duration of such letter(s) of credit shall comply with Program Obligations.


  1. Borrower shall complete and/or cause to be completed to the satisfaction of Lender and HUD, the Off-site Construction, free of all liens and assessments, including liens and assessments against the Mortgaged Property, on or before the Completion Date. Borrower shall remedy or cause to be remedied, to the satisfaction of HUD, (a) all defects in the Off-site Construction due to faulty materials, faulty workmanship, or defective materials, and (b) all damage to the Project resulting from such defects, which defects or damage become apparent within twelve (12) months from completion of the Off-site Construction (“Latent Defects”).


  1. If the Drawings and Specifications provide that the Off-site Construction or any part thereof shall be performed by the municipality or political subdivision in which the Mortgaged Property lies, then such proportionate amount of the Escrow that is attributable to the portion of the Off-site Construction to be performed by said municipality or political subdivision, shall be held by the Lender and applied in payment of any special assessment which may be levied against the Mortgaged Property by reason of such improvement, and if not so levied or assessed, or to be so levied or assessed, may be released to the Borrower subject to Paragraph 7 of this Agreement.


  1. Disbursements from the Escrow shall be made only upon prior written approval of HUD, with the exception of those amounts expended by Lender pursuant to Paragraph 6 of this Agreement, to meet any established cost of the Off-site Construction for which the Escrow was intended. The sum to which the Borrower shall be entitled to receive under any disbursement requested pursuant to this paragraph shall be the cost of the portions of Off-site Construction acceptably completed, as approved by Lender and HUD, less ten percent (10%) and less prior disbursements of Escrow funds.


  1. In the event Borrower has not completed and/or caused to be completed all the Off-site Construction by the Completion Date, and upon receiving written instructions from HUD, Lender shall proceed to complete the Off-site Construction in accordance with the Drawings and Specifications, and to pay the cost thereof, including all costs and a reasonable fee of the Lender, from the Escrow. For this purpose, Borrower irrevocably appoints Lender as its attorney-in-fact, with full power of substitution, to do and perform for Borrower in Borrower’s name, place and stead, all matters and things which Lender shall in its judgment deem necessary and proper to effectuate the completion of the Off-site Construction in accordance with the Drawings and Specifications, and to apply the amount deposited under the Escrow to the payment of debts, expenses, costs and charges of any kind contracted or incurred in connection therewith. The orders given by Lender as attorney-in-fact for Borrower shall be good and sufficient vouchers for all payments made by virtue thereof. In this connection, this power of attorney shall provide Lender with full and sufficient authority to enter into and upon the location of the Off-site Construction and take charge thereof, together with all materials, equipment and other improvements and to call upon and require contractors to complete the Off-site Construction. Except for intentional misconduct or gross negligence on the part of Lender, Borrower shall indemnify, hold harmless and defend Lender from and against claims of third parties arising from Lender’s performance under this paragraph. Lender shall have the right to obtain any property and/or liability insurance coverage which Lender shall in its judgment deem necessary or appropriate in connection with Lender’s performance under this paragraph. Subject to written HUD approval, Lender may extend the Completion Date. Lender will not be responsible for performance of the Off-site Construction beyond the expenditure of the amount available from the Escrow, and if that amount is insufficient, Lender will be under no obligation to proceed further with the Off-site Construction. The power granted herein is coupled with an interest, and Borrower acknowledges and agrees that all powers granted herein to Lender may be assigned to HUD.


  1. Subject to Paragraph 6 of this Agreement, at Borrower’s written request and with written HUD approval in accordance with Program Obligations, any balance remaining in the Escrow will be released to Borrower provided the following conditions are met:

  1. thirty (30) days have passed since the completion of the Off-site Construction required by the Drawings and Specifications to the satisfaction of Lender and HUD;


  1. no liens or assessments have been placed against the site of the Off-site Construction or the Mortgaged Property;


  1. an Event of Default does not then exist.


  1. The Escrow, when in the form of cash, shall be held by Lender or a depository institution satisfactory to the Lender and in accordance with Program Obligations. Lender may, at any time, for any reason or no reason, draw upon any letter of credit included in the Escrow and convert the same to cash, which cash shall then be held and disbursed pursuant to the terms of this Agreement. Fees charged by Lender and any interest earned on the Escrow shall be governed by Program Obligations.


  1. The Escrow may, at HUD’s direction, be subject to immediate application to the Indebtedness if an Event of Default by Borrower occurs at any time.



Each signatory below hereby certifies such signatory’s statements and representations contained in this Agreement and all supporting documentation provided by such signatory are true, accurate, and complete. This Agreement has been made, presented, and delivered for the purpose of influencing an official action of HUD in insuring the Loan, and may be relied upon by HUD as a true statement of the facts contained therein.


IN WITNESS WHEREOF, the parties have duly executed this Escrow Agreement for Off-site Facilities as of the day and year first above written.


BORROWER: LENDER:

_________________________ ________________________

By_______________________ By______________________

_________________________ ________________________

Print Name and Title Print Name and Title


DEPOSITORY INSTITUTION:

_________________________

By_______________________

_________________________

Print Name and Title



Attachments: Exhibit “A”

Exhibit “B”

EXHIBIT “A”

Off-site Construction Supporting Description and Cost Estimate



EXHIBIT “B”

Form of Letter of Credit


Shape1 Previous versions obsolete Page 5 of 5 form HUD-91071-ORCF (03/2018)

File Typeapplication/vnd.openxmlformats-officedocument.wordprocessingml.document
AuthorHendrich, Nicole M
File Modified0000-00-00
File Created2021-01-15

© 2024 OMB.report | Privacy Policy