2900-0422 - 60-Day FRN 90 FR 44907 - 17SEP2025

Federal Register / Vol. 90, No. 178 / Wednesday, September 17, 2025 / Notices
Comments and
recommendations for the proposed
information collection should be sent by
September 17, 2025.

DATES:

To submit comments and
recommendations for the proposed
information collection, please type the
following link into your browser:
www.reginfo.gov/public/do/PRAMain,
select ‘‘Currently under Review—Open
for Public Comments’’, then search the
list for the information collection by
Title or ‘‘OMB Control No. 2900–0521.’’

ADDRESSES:

Dorothy Glasgow,
Acting, VA PRA Clearance Officer, Office of
Enterprise and Integration, Data Governance
Analytics, Department of Veterans Affairs.
[FR Doc. 2025–17980 Filed 9–16–25; 8:45 am]
BILLING CODE 8320–01–P

DEPARTMENT OF VETERANS
AFFAIRS
[OMB Control No. 2900–0918]

Dorothy Glasgow, 202–461–1084,
[email protected].

Agency Information Collection Activity
Under OMB Review: Veterans Affairs
Life Insurance (VALife) Policy
Maintenance Application

SUPPLEMENTARY INFORMATION:

AGENCY:

FOR FURTHER INFORMATION CONTACT:

lotter on DSK11XQN23PROD with NOTICES1

Authority: 44 U.S.C. 3501 et seq.

Title: Certification of Loan
Disbursement, Request for Verification
of Employment and Request for
Verification of Deposit (VA Form 26–
1820, VA Form 26–8497, VA Form 26–
8497a).
OMB Control Number: 2900–0521
https://www.reginfo.gov/public/do/
PRASearch.
Type of Review: Revision of a
currently approved collection.
Abstract: VA Form 26–1820 is used
for loans closed on the prior approval
and automatic basis. Lenders complete
and submit this form to close VA loans
under 38 U.S.C. 3710 and thereby
complies with the provisions of 38
U.S.C. 3702(c) which requires lenders to
report to the Secretary on loans
guaranteed or insured.
In addition, certifications that are to
be provided to the Veteran were added
that were included in OMB Control
#2900–0144. The respondent burden
has decreased due to the estimate
number of respondents.
An agency may not conduct or
sponsor, and a person is not required to
respond to a collection of information
unless it displays a currently valid OMB
control number.
The Federal Register Notice with a
60-day comment period soliciting
comments on this collection of
information was published at 90 FR
31581, July 14, 2025.
Affected Public: Individuals or
Households.
Estimated Number of Respondents:
464,000.
Frequency of Response: Annually.
Estimated Annual Burden: 154,475
hours.
Estimated Average Burden per
Respondent: 35 minutes.

VerDate Sep<11>2014

16:58 Sep 16, 2025

Jkt 265001

Veterans Benefits
Administration, Department of Veterans
Affairs.
ACTION: Notice.
In compliance with the
Paperwork Reduction Act (PRA) of
1995, this notice announces that the
Veterans Benefits Administration,
Department of Veterans Affairs, will
submit the collection of information
abstracted below to the Office of
Management and Budget (OMB) for
review and comment. The PRA
submission describes the nature of the
information collection and its expected
cost and burden, and it includes the
actual data collection instrument.
DATES: Comments and
recommendations for the proposed
information collection should be sent by
October 17, 2025.
ADDRESSES: To submit comments and
recommendations for the proposed
information collection, please type the
following link into your browser:
www.reginfo.gov/public/do/PRAMain,
select ‘‘Currently under Review—Open
for Public Comments’’, then search the
list for the information collection by
Title or ‘‘OMB Control No. 2900–0918.’’
FOR FURTHER INFORMATION CONTACT: VA
PRA information: Dorothy Glasgow,
(202) 461–1084, [email protected].
SUPPLEMENTARY INFORMATION:
Title: Veterans Affairs Life Insurance
(VALife) Policy Maintenance
Application, VA Form 29–10279.
OMB Control Number: 2900–0918
https://www.reginfo.gov/public/do/
PRASearch.
Type of Review: Extension without
change of a currently approved
collection.
Abstract: This form is used by the
Department of Veterans Affairs to allow
authorized agents (Guardian, POA, VA
Fiduciary) to update information on a
Veteran’s VALife policy. The form is
authorized by 38 U.S.C. 1922.
SUMMARY:

PO 00000

Frm 00109

Fmt 4703

Sfmt 4703

44907

An agency may not conduct or
sponsor, and a person is not required to
respond to a collection of information
unless it displays a currently valid OMB
control number. The Federal Register
Notice with a 60-day comment period
soliciting comments on this collection
of information was published at 90 FR
31582, July 14, 2025.
Affected Public: Individuals or
Households.
Estimated Annual Burden: 417 hours.
Estimated Average Burden per
Respondent: 10 minutes.
Frequency of Response: example: On
occasion.
Estimated Number of Respondents:
2,500.
Authority: 44 U.S.C. 3501 et seq.
Dorothy Glasgow,
Acting, VA PRA Clearance Officer, Office of
Enterprise and Integration, Data Governance
Analytics, Department of Veterans Affairs.
[FR Doc. 2025–17945 Filed 9–16–25; 8:45 am]
BILLING CODE 8320–01–P

DEPARTMENT OF VETERANS
AFFAIRS
[OMB Control No. 2900–0422]

Agency Information Collection
Activity: VAAR Construction
Provisions and Clauses
Office of Acquisition and
Logistics, Department of Veterans
Affairs.
ACTION: Notice.
AGENCY:

Office of Acquisition and
Logistics (OAL), Department of Veterans
Affairs (VA), is announcing an
opportunity for public comment on the
proposed collection of certain
information by the agency. Under the
Paperwork Reduction Act (PRA) of
1995, Federal agencies are required to
publish notice in the Federal Register
concerning each proposed collection of
information, including each proposed
extension of a currently approved
collection, and allow 60 days for public
comment in response to the notice.
DATES: Written comments and
recommendations on the proposed
collection of information should be
received on or before November 17,
2025.
SUMMARY:

Comments must be
submitted through
www.Regulations.gov.

ADDRESSES:

FOR FURTHER INFORMATION CONTACT:

Program-Specific Information: Forrest
Browne, 202–632–9677,
[email protected].

E:\FR\FM\17SEN1.SGM

17SEN1

44908

Federal Register / Vol. 90, No. 178 / Wednesday, September 17, 2025 / Notices

VA PRA Information: Dorothy
Glasgow, 202–461–1084, VAPRA@
va.gov.
Under the
PRA of 1995, Federal agencies must
obtain approval from the Office of
Management and Budget (OMB) for each
collection of information they conduct
or sponsor. This request for comment is
being made pursuant to Section
3506(c)(2)(A) of the PRA.
With respect to the following
collection of information, OAL invites
comments on: (1) whether the proposed
collection of information is necessary
for the proper performance of OAL’s
functions, including whether the
information will have practical utility;
(2) the accuracy of OAL’s estimate of the
burden of the proposed collection of
information; (3) ways to enhance the
quality, utility, and clarity of the
information to be collected; and (4)
ways to minimize the burden of the
collection of information on
respondents, including through the use
of automated collection techniques or
the use of other forms of information
technology.
Title: VAAR Construction Provisions
and Clauses.
OMB Control Number: 2900–0422.
https://www.reginfo.gov/public/do/
PRASearch (Once at this link, you can
enter the OMB Control Number to find

lotter on DSK11XQN23PROD with NOTICES1

SUPPLEMENTARY INFORMATION:

VerDate Sep<11>2014

16:58 Sep 16, 2025

Jkt 265001

the historical versions of this
Information Collection).
Type of Review: Extension without
change of a currently approved
collection.
Abstract: This Paperwork Reduction
Act (PRA) submission seeks renewal
without changes of Office of
Management and Budget (OMB)
approval No. 2900–0422 for five
collections of information for the
Department of Veterans Affairs
Acquisition Regulation (VAAR) clauses,
as follows:
• Clause 852.232–70, Payment Under
Fixed-Price Construction Contracts
(without NAS–CPM), requires
construction contractors not using
Network Analysis System-Critical Path
Method (NAS–CPM), to submit a
schedule of costs for work to be
performed under the contract.
• Clause 852.232–71, Payment Under
Fixed-Price Construction Contracts
(including NAS–CPM), requires
construction contractors using NAS–
CPM, to submit a schedule of costs for
work to be performed under the
contract.
• Clause 852.236–72, Performance of
Work by the Contractor, requires
contractors awarded a construction
contract containing Federal Acquisition
Regulation clause 52.236–1,
Performance of Work by the Contractor,
to submit a statement designating the
branch or branches of contract work to

PO 00000

Frm 00110

Fmt 4703

Sfmt 9990

be performed by the contractor’s own
forces.
• Clause 852.236–80, Subcontracts
and Work Coordination, requires
construction contractors, on contracts
involving complex mechanicalelectrical work, to furnish coordination
drawings showing the manner in which
utility lines will fit into available space
and relate to each other and to the
existing building elements.
• Clause 852.243–70, Construction
Contract Changes-Supplement, requires
contractors to submit cost proposals for
changes ordered by the contracting
officer or for changes proposed by the
contractor.
Affected Public: Business or other forprofit.
Estimated Annual Burden: 2,974
hours.
Estimated Average Burden per
Respondent: 105 minutes.
Frequency of Response: More than
quarterly.
Estimated Number of Respondents:
1,706.
(Authority: 44 U.S.C. 3501 et seq.)
Lanea Haynes,
Acting, VA PRA Clearance Officer, (Alt) Office
of Enterprise and Integration/Data
Governance Analytics, Department of
Veterans Affairs.
[FR Doc. 2025–17968 Filed 9–16–25; 8:45 am]
BILLING CODE 8320–01–P

E:\FR\FM\17SEN1.SGM

17SEN1