Certain Federal Acquisition Regulation Part 36 Construction Contract Requirements; FAR Sections Affected: 52.236-5, 52.236-13 Alternate I, 52.236-15, and 52.236-19

This justification supports clearance of an extension of the collection and consolidating it with OMB control number 9000-0062, and covers the information that contractors must submit to comply with the following FAR requirements: ● FAR 52.236-5, Material and Workmanship. This clause requires contractors to obtain contracting officer approval of the machinery, equipment, material, or articles to be incorporated into the work. The contractor’s request must include: the manufacturer’s name, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment; and full information concerning the material or articles. When directed by the contracting officer, the contractor must submit samples of the items requiring approval for incorporating into the work. ● FAR 52.236-13, Accident Prevention, Alternate I. This alternate to the basic clause requires contractors to submit a written proposed plan to provide and maintain work environments and procedures that will safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to contractor operations and activities; avoid interruptions of Government operations and delays in project completion dates; and control costs in the performance of this contract. The plan must include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards. ● FAR 52.236-15, Schedules for Construction Contracts. This clause requires contractors to prepare and submit to the contracting officer for approval three copies of a practicable schedule showing the order in which the contractor proposes to perform the work, and the dates on which the contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). ● FAR 52.236-19, Organization and Direction of the Work. This clause requires contractors, under cost-reimbursement construction contracts, to submit to the contracting officer a chart showing the general executive and administrative organization, the personnel to be employed in connection with the work under the contract, and their respective duties. The contractor must keep the data furnished current by supplementing it as additional information becomes available.

The latest form for Certain Federal Acquisition Regulation Part 36 Construction Contract Requirements; FAR Sections Affected: 52.236-5, 52.236-13 Alternate I, 52.236-15, and 52.236-19 expires 2027-04-30 and is listed under ICR 202403-9000-001.

Organization and Direction of the Work

Federal Enterprise Architecture: Supply Chain Management - Goods Acquisition