HUD 5370-EZ General Contract Conditions for Small Contructions/Devel

U.S. Department of Housing and Urban
Development
Office of Public and Indian Housing

General Contract Conditions for
Small Construction/Development
Contracts

OMB Approval No. 2577-0157 (exp. 3/31/2010)

Applicability. The following contract clauses are applicable and
must be inserted into small construction/development contracts,
greater than $2,000 but not more than $100,000.
1. Definitions
Terms used in this form are the same as defined in form HUD-5370
2. Prohibition Against Liens
The Contractor is prohibited from placing a lien on the PHA’s
property. This prohibition shall apply to all subcontractors at any
tier and all materials suppliers. The only liens on the PHA’s
property shall be the Declaration of Trust or other liens approved
by HUD.
3. Disputes
(a) Except for disputes arising under the Labor Standards
clauses, all disputes arising under or relating to this contract,
including any claims for damages for the alleged breach thereof
which are not disposed of by agreement, shall be resolved
under this clause.
(b) All claims by the Contractor shall be made in writing and
submitted to the Contracting Officer for a written decision. A
claim by the PHA against the Contractor shall be subject to a
written decision by the Contracting Officer.
(c) The Contracting Officer shall, within 30 days after receipt of
the request, decide the claim or notify the Contractor of the date
by which the decision will be made.
(d) The Contracting Officer’s decision shall be final unless the
Contractor (1) appeals in writing to a higher level in the PHA in
accordance with the PHA’s policy and procedures, (2) refers
the appeal to an independent mediator or arbitrator, or (3) files
suit in a court of competent jurisdiction. Such appeal must be
made within 30 days after receipt of the Contracting Officer’s
decision.
(e) The Contractor shall proceed diligently with performance of
this contract, pending final resolution of any request for relief,
claim, appeal, or action arising under or relating to the contract,
and comply with any decision of the Contracting Officer.
4. Default
(a) If the Contractor refuses or fails to prosecute the work, or any
separable part thereof, with the diligence that will insure its
completion within the time specified in this contract, or any
extension thereof, or fails to complete said work within this
time, the Contracting Officer may, by written notice to the
Contractor, terminate the right to proceed with the work (or
separable part of the work) that has been delayed. In the event,
the PHA may take over the work and complete it by contract or
otherwise, and may take possession of and use any materials,
equipment, and plant on the work site necessary for completing
the work. The Contractor and its sureties shall be liable for any
damage to the PHA resulting from the Contractor’s refusal or
failure to complete the work within the specified time, whether
or not the Contractor’s right to proceed with the work is
terminated. This liability includes any increased costs incurred
by the PHA in completing the work.

(b) The Contractor’s right to proceed shall not be terminated or the
Contractor charged with damages under this clause if –
(1) The delay in completing the work arises from
unforeseeable causes beyond the control and without the
fault or negligence of the Contractor; and
(2) The Contractor, within 10 days from the beginning of such
delay notifies the Contracting Officer in writing of the
causes of delay. The Contracting Officer shall ascertain
the facts and the extent of the delay. If, in the judgment of
the Contracting Officer, the findings of Fact warrant such
action, time for completing the work shall be extended by
written modification to the contract. The findings of the
Contracting Officer shall be reduced to a written decision
which shall be subject to the provisions of the Disputes
clause of this contract.
(c) If, after termination of the Contractor’s right to proceed, it is
determined that the Contractor was not in default, or that the
delay was excusable, the rights and obligation of the parties will
be the same as if the termination had been for convenience of
the PHA.
5. Termination for Convenience
(a) The Contracting Officer may terminate this contract in whole,
or in part, whenever the Contracting Officer determines that
such termination is in the best interest of the PHA. Any such
termination shall be effected by delivery to the Contractor of a
Notice of Termination specifying the extent to which the
performance of the work under the contract is terminated, and
the date upon which such termination becomes effective.
(b) If the performance of the work is terminated, either in whole or
in part, the PHA shall be liable to the Contractor for reasonable
and proper costs resulting from such termination upon the
receipt by the PHA of a properly presented claim setting out in
detail: (1) the total cost of the work performed to date of
termination less the total amount of contract payments made to
the Contractor; (2) the cost (including reasonable profit) of
settling and paying claims under subcontracts and material
orders for work performed and materials and supplies delivered
to the site, payment for which has not been made by the PHA to
the Contractor or by the Contractor to the subcontractor or
supplier; (3) the cost of preserving and protecting the work
already performed until the PHA or assignee takes possession
thereof or assumes responsibility therefore; (4) the actual or
estimated cost of legal and accounting services reasonably
necessary to prepare and present the termination claim to the
PHA; and (5) an amount constituting a reasonable profit on the
value of the work performed by the Contractor.
(c) The Contracting Officer will act on the Contractor’s claim
within days (60 days unless otherwise indicated) of receipt of
the Contractor’s claim.
(d) Any disputes with regard to this clause are expressly made
subject to the provisions of the Disputes clause of this contract.
6. Insurance
(a) Before commencing work, the Contractor and each subcontractor shall furnish the PHA with certificates of insurance
showing the following insurance is in force and will insure all
operations under the Contract:

Page 1 of 7

Form HUD-5370-EZ (10/2006)

(1) Workers’ Compensation, in accordance with state or Territorial Workers’ Compensation laws.
(2) Commercial General Liability with a combined single limit
for bodily injury and property damage of not less than $________
[Contracting Officer insert amount] per occurrence to protect the
Contractor and each subcontractor against claims for bodily injury
or death and damage to the property of others. This shall cover the
use of all equipment, hoists, and vehicles on the site(s) not covered
by Automobile Liability under (3) below. If the Contractor has a
“claims-made” policy, then the following additional requirements
apply: the policy must provide a “retroactive date” which must be
on or before the execution date of the Contract; and the extended
reporting period may not be less than five years following the
completion date of the Contract.
(3) Automobile Liability on owned and non -owned motor
vehicles used on the site(s) or in connection therewith for a
combined single limit for bodily injury and property damage of not
less than $______ [Contracting Officer insert amount] per
occurrence.
(b) Before commencing work, the Contractor shall furnish the PHA
with a certificate of insurance evidencing that Builder’s Risk
(fire and extended coverage) Insurance on all work in place
and/or materials stored at the building site(s), including
foundations and building equipment, is in force. The Builder’s
Risk Insurance shall be for the benefit of the Contractor and the
PHA as their interests may appear and each shall be named in
the policy or policies as an insured. The Contractor in installing
equipment supplied by the PHA shall carry insurance on such
equipment from the time the Contractor takes possession thereof
until the Contract work is accepted by the PHA. The Builder’s
Risk Insurance need not be carried on excavations, piers,
footings, or foundations until such time as work on the superstructure is started. It need not be carried on landscape work.
Policies shall furnish coverage at all times for the full cash value
of all completed construction, as well as materials in place
and/or stored at the site(s), whether or not partial payment has
been made by the PHA. The Contractor may terminate this
insurance on buildings as of the date taken over for occupancy
by the PHA. The Contractor is not required to carry Builder’s
Risk Insurance for modernization work which does not involve
structural alterations or additions and where the PHA’s existing
fire and extended coverage policy can be endorsed to include
such work.
(c) All insurance shall be carried with companies which are
financially responsible and admitted to do business in the State
in which the project is located. If any such insurance is due to
expire during the construction period, the Contractor (including
subcontractors, as applicable) shall not permit the coverage to
lapse and shall furnish evidence of coverage to the Contracting
Officer. All certificates of insurance, as evidence of coverage,
shall provide that no coverage may be canceled or non-renewed
by the insurance company until at least 30 days prior written
notice has been given to the Contracting Officer.
7. Contract Modifications
(a) Only the Contracting Officer has authority to modify any term
or condition of this contract. Any contract modification shall be
authorized in writing.
(b) The Contracting Officer may modify the contract unilaterally
(1) pursuant to a specific authorization stated in a contract
clause (e.g., Changes); or (2) for administrative matters which

do not change the rights or responsibilities of the parties (e.g.,
change in the PHA address). All other contract modifications
shall be in the form of supplemental agreements signed by the
Contractor and the Contracting Officer.
(c) When a proposed modification requires the approval of HUD
prior to its issuance (e.g., a change order that exceeds the PHA’s
approved threshold), such modification shall not be effective
until the required approval is received by the PHA.
8. Changes
(a) The Contracting Officer may, at any time, without notice to the
sureties, by written order designated or indicated to be a change
order, make changes in the work within the general scope of the
contract including changes:
(1) In the specifications (including drawings and designs);
(2) In the method or manner of performance of the work;
(3) PHA-furnished facilities, equipment, materials, services, or
site; or,
(4) Directing the acceleration in the performance of the work.
(b) Any other written order or oral order (which, as used in this
paragraph (b), includes direction, instruction, interpretation, or
determination) from the Contracting Officer that causes a change
shall be treated as a change order under this clause; provided,
that the Contractor gives the Contracting Officer written notice
stating (1) the date, circumstances and source of the order and (2)
that the Contractor regards the order as a change order.
(c) Except as provided in this clause, no order, statement or conduct
of the Contracting Officer shall be treated as a change under this
clause or entitle the Contractor to an equitable adjustment.
(d) If any change under this clause causes an increase or decrease
in the Contractor’s cost of, or the time required for the performance of any part of the work under this contract, whether or
not changed by any such order, the Contracting Officer shall
make an equitable adjustment and modify the contract in
writing. However, except for a adjustment based on defective
specifications, no proposal for any change under paragraph (b)
above shall be allowed for any costs incurred more than 20
days (5 days for oral orders) before the Contractor gives written
notice as required. In the case of defective specifications for
which the PHA is responsible, the equitable adjustment shall
include any increased cost reasonably incurred by the
Contractor in attempting to comply with the defective
specifications.
(e) The Contractor must assert its right to an adjustment under this
clause within 30 days after (1) receipt of a written change order
under paragraph (a) of this clause, or (2) the furnishing of a
written notice under paragraph (b) of this clause, by submitting
a written statement describing the general nature and the
amount of the proposal. If the facts justify it, the Contracting
Officer may extend the period for submission. The proposal
may be included in the notice required under paragraph (b)
above. No proposal by the Contractor for an equitable adjustment shall be allowed if asserted after final payment under this
contract.
(f) The Contractor’s written proposal for equitable adjustment shall
be submitted in the form of a lump sum proposal supported
with an itemized breakdown of all increases and decreases in
the contract in at least the following details:
(1) Direct Costs. Materials (list individual items, the quantity
and unit cost of each, and the aggregate cost); Transportation and delivery costs associated with materials; Labor

Page 2 of 7

Form HUD-5370-EZ (10/2006)

breakdowns by hours or unit costs (identified with specific
work to be performed); Construction equipment exclusively
necessary for the change; Costs of preparation and/ or
revision to shop drawings resulting from the change;
Worker’s Compensation and Public Liability Insurance;
Employment taxes under FICA and FUTA; and, Bond
Costs - when size of change warrants revision.
(2) Indirect Costs. Indirect costs may include overhead, general
and administrative expenses, and fringe benefits not normally
treated as direct costs.
(3) Profit. The amount of profit shall be negotiated and may vary
according to the nature, extent, and complexity of the work
required by the change.
The allowability of the direct and indirect costs shall be determined
in accordance with the Contract Cost Principles and Procedures for
Commercial Firms in Part 31 of the Federal Acquisition Regulation
(48 CFR 1-31), as implemented by HUD Handbook 2210.18, in
effect on the date of this contract. The Contractor shall not be
allowed a profit on the profit received by any subcontractor.
Equitable adjustments for deleted work shall include a credit for
profit and may include a credit for indirect costs. On proposals
covering both increases and decreases in the amount of the
contract, the application of indirect costs and profit shall be on the
net-change in direct costs for the Contractor or subcontractor
performing the work.
(g) The Contractor shall include in the proposal its request for time
extension (if any), and shall include sufficient information and
dates to demonstrate whether and to what extent the change
will delay the completion of the contract in its entirety.
(h) The Contracting Officer shall act on proposals within 30 days
after their receipt, or notify the Contractor of the date when
such action will be taken.
(i) Failure to reach an agreement on any proposal shall be a dispute
under the clause entitled Disputes herein. Nothing in this clause,
however, shall excuse the Contractor from proceeding with the
contract as changed.
(j) Except in an emergency endangering life or property, no change
shall be made by the Contractor without a prior order from the
Contracting Officer.
9. Examination and Retention of Contractor’s Records
The HA, HUD, or Comptroller General of the United States, or any
of their duly authorized representatives shall, until three years after
final payment under this contract, have access to and the right to
examine any of the Contractor’s directly pertinent books,
documents, papers, or other records involving transactions related
to this contract for the purpose of making audit, examination,
excerpts, and transcriptions.
10. Rights in Data and Patent Rights (Ownership and
Proprietary Interest)
The HA shall have exclusive ownership of, all proprietary interest
in, and the right to full and exclusive possession of all information,
materials, and documents discovered or produced by Contractor
pursuant to the terms of this Contract, including but not limited to
reports, memoranda or letters concerning the research and reporting
tasks of this Contract.
11. Energy Efficiency

The Contractor shall comply with all mandatory standards and
policies relating to energy efficiency which are contained in the
energy conservation plan issued in compliance with the Energy
Policy and Conservation Act (Pub.L. 94-163) for the State in which
the work under this contract is performed.
12. Procurement of Recovered Materials
(a) In accordance with Section 6002 of the Solid Waste Disposal
Act, as amended by the Resource Conservation and Recovery
Act, the Contractor shall procure items designated in guidelines
of the Environmental Protection Agency (EPA) at 40 CFR Part
247 that contain the highest percentage of recovered materials
practicable, consistent with maintaining a satisfactory level of
competition. The Contractor shall procure items designated in
the EPA guidelines that contain the highest percentage of
recovered materials practicable unless the Contractor
determines that such items: (1) are not reasonably available in a
reasonable period of time; (2) fail to meet reasonable
performance standards, which shall be determined on the basis
of the guidelines of the National Institute of Standards and
Technology, if applicable to the item; or (3) are only available
at an unreasonable price.
(b) Paragraph (a) of this clause shall apply to items purchased
under this contract where: (1) the Contractor purchases in
excess of $10,000 of the item under this contract; or (2) during
the preceding Federal fiscal year, the Contractor: (i) purchased
any amount of the items for use under a contract that was
funded with Federal appropriations and was with a Federal
agency or a State agency or agency of a political subdivision of
a State; and (ii) purchased a total of in excess of $10,000 of the
item both under and outside that contract.
13. Training and Employment Opportunities for Residents in
the Project Area (Section 3, HUD Act of 1968; 24 CFR 135)
(a) The work to be performed under this contract is subject to the
requirements of section 3 of the Housing and Urban
Development Act of 1968, as amended, 12 U.S.C. 1701u
(section 3). The purpose of section 3 is to ensure that
employment and other economic opportunities generated by
HUD assistance or HUD-assisted projects covered by section 3,
shall, to the greatest extent feasible, be directed to low- and
very low-income persons, particularly persons who are
recipients of HUD assistance for housing.
(b) The parties to this contract agree to comply with HUD's
regulations in 24 CFR Part 135, which implement section 3. As
evidenced by their execution of this contract, the parties to this
contract certify that they are under no contractual or other
impediment that would prevent them from complying with the
Part 135 regulations.
(c) The contractor agrees to send to each labor organization or
representative of workers with which the contractor has a
collective bargaining agreement or other understanding, if any,
a notice advising the labor organization or workers'
representative of the contractor's commitments under this
section 3 clause, and will post copies of the notice in
conspicuous places at the work site where both employees and
applicants for training and employment positions can see the
notice. The notice shall describe the section 3 preference, shall
set forth minimum number and job titles subject to hire,
availability of apprenticeship and training positions, the

Page 3 of 7

Form HUD-5370-EZ (10/2006)

qualifications for each; and the name and location of the
person(s) taking applications for each of the positions; and the
anticipated date the work shall begin.
(d) The contractor agrees to include this section 3 clause in every
subcontract subject to compliance with regulations in 24 CFR
Part 135, and agrees to take appropriate action, as provided in
an applicable provision of the subcontract or in this section 3
clause, upon a finding that the subcontractor is in violation of
the regulations in 24 CFR Part 135. The contractor will not
subcontract with any subcontractor where the contractor has
notice or knowledge that the subcontractor has been found in
violation of the regulations in 24 CFR Part 135.
(e) The contractor will certify that any vacant employment
positions, including training positions, that are filled (1) after
the contractor is selected but before the contract is executed,
and (2) with persons other than those to whom the regulations
of 24 CFR Part 135 require employment opportunities to be
directed, were not filled to circumvent the contractor's
obligations under 24 CFR Part 135.
(f) Noncompliance with HUD's regulations in 24 CFR Part 135
may result in sanctions, termination of this contract for default,
and debarment or suspension from future HUD assisted
contracts.
14. Labor Standards - Davis-Bacon and Related Acts
(a) Minimum Wages.
(1) All laborers and mechanics employed under this contract in
the construction or development of the project(s) involved will
be paid unconditionally and not less often than once a week,
and without subsequent deduction or rebate on any account
(except such payroll deductions as are permitted by regulations
issued by the Secretary of Labor under the Copeland Act (29
CFR Part 3)), the full amount of wages and bona fide fringe
benefits (or cash equivalents thereof) due at time of payment
computed at rates not less than those contained in the wage
determination of the Secretary of Labor which is attached
hereto and made a part hereof, regardless of any contractual
relationship which may be alleged to exist between the
Contractor and such laborers and mechanics. Contributions
made or costs reasonably anticipated for bona fide fringe
benefits under Section 1(b)(2) of the Davis-Bacon Act on
behalf of laborers or mechanics are considered wages paid to
such laborers or mechanics, subject to the provisions of 29
CFR 5.5(a)(1)(iv); also, regular contributions made or costs
incurred for more than a weekly period (but not less often than
quarterly) under plans, funds, or programs which cover the
regular weekly period, are deemed to be constructively made
or incurred during such weekly period. Such laborers and
mechanics shall be paid the appropriate wage rate and fringe
benefits in the wage determination for the classification of
work actually performed, without regard to skill, except as
provided in 29 CFR 5.5(a)(4). Laborers or mechanics
performing work in more than one classification may be
compensated at the rate specified for each classification for the
time actually worked therein; provided, that the employer’s
payroll records accurately set forth the time spent in each
classification in which work is performed. The wage
determination (including any additional classification and
wage rates conformed under 29 CFR 5.5(a)(1)(ii) and the
Davis-Bacon poster (WH-1321) shall be posted at all times by
the Contractor and its subcontractors at the site of the work in

Page 4 of 7

a prominent and accessible place where it can be easily seen
by the workers.
(2) (i) Any class of laborers or mechanics, including helpers,
which is not listed in the wage determination and
which is to be employed under the contract shall be
classified in conformance with the wage
determination. HUD shall approve an additional
classification and wage rate and fringe benefits
therefor only when all the following criteria have been
met:
(a) The work to be performed by the classification
requested is not performed by a classification in the
wage determination; and
(b) The classification is utilized in the area by the
construction industry; and
(c) The proposed wage rate, including any bona fide
fringe benefits, bears a reasonable relationship to
the wage rates contained in the wage
determination.
(ii) If the Contractor and the laborers and mechanics to be
employed in the classification (if known), or their
representatives, and HUD or its designee agree on the
classification and wage rate (including the amount
designated for fringe benefits where appropriate), a
report of the action shall be sent by HUD or its
designee to the Administrator of the Wage and Hour
Division, Employee Standards Administration, U.S.
Department of Labor, Washington, DC 20210. The
Administrator, or an authorized representative, will
approve, modify, or disapprove every additional
classification action within 30 days of receipt and so
advise HUD or its designee or will notify HUD or its
designee within the 30-day period that additional time
is necessary.
(iii) In the event the Contractor, the laborers or mechanics
to be employed in the classification or their
representatives, and HUD or its designee do not agree
on the proposed classification and wage rate (including
the amount designated for fringe benefits, where
appropriate), HUD or its designee shall refer the
questions, including the views of all interested parties
and the recommendation of HUD or its designee, to
the Administrator of the Wage and Hour Division for
determination. The Administrator, or an authorized
representative, will issue a determination within 30
days of receipt and so advise HUD or its designee or
will notify HUD or its designee within the 30-day
period that additional time is necessary.
(iv) The wage rate (including fringe benefits where
appropriate) determined pursuant to subparagraphs
(a)(2)(ii) or (iii) of this clause shall be paid to all
workers performing work in the classification under
this contract from the first day on which work is
performed in the classification.
(3) Whenever the minimum wage rate prescribed in the
contract for a class of laborers or mechanics includes a
fringe benefit which is not expressed as an hourly rate,
the Contractor shall either pay the benefit as stated in the
wage determination or shall pay another bona fide fringe
benefit or an hourly cash equivalent thereof.
(4) If the Contractor does not make payments to a trustee
or other third person, the Contractor may consider as part

Form HUD-5370-EZ (10/2006)

of the wages of any laborer or mechanic the amount of
any costs reasonably anticipated in providing bona fide
fringe benefits under a plan or program; provided, that
the Secretary of Labor has found, upon the written
request of the Contractor, that the applicable standards of
the Davis-Bacon Act have been met. The Secretary of
Labor may require the Contractor to set aside in a
separate account assets for the meeting of obligations
under the plan or program.
(b) Withholding of Funds. HUD or its designee shall, upon
its own action or upon written request of an authorized
representative of the Department of Labor, withhold or
cause to be withheld from the Contractor under this
contract or any other Federal contract with the same
prime Contractor, or any other Federally-assisted contract
subject to Davis-Bacon prevailing wage requirements,
which is held by the same prime Contractor, so much of
the accrued payments or advances as may be considered
necessary to pay laborers and mechanics, including
apprentices, trainees, and helpers, employed by the
Contractor or any subcontractor the full amount of wages
required by the contract. In the event of failure to pay any
laborer or mechanic, including any apprentice, trainee, or
helper, employed or working in the construction or
development of the project, all or part of the wages
required by the contract, HUD or its designee may, after
written notice to the Contractor, take such action as may
be necessary to cause the suspension of any further
payment, advance, or guarantee of funds until such
violations have ceased. HUD or its designee may, after
written notice to the Contractor, disburse such amounts
withheld for and on account of the Contractor or
subcontractor to the respective employees to whom they
are due.
(c) Payrolls and Basic Records.
(1) Payrolls and basic records relating thereto shall be
maintained by the Contractor during the course of the work
and preserved for a period of three years thereafter for all
laborers and mechanics working in the construction or
development of the project. Such records shall contain the
name, address, and social security number of each such
worker, his or her correct classification, hourly rates of
wages paid (including rates of contributions or costs
anticipated for bona fide fringe benefits or cash equivalents
thereof of the types described in section 1(b)(2)(B) of the
Davis-Bacon Act), daily and weekly number of hours
worked, deductions made, and actual wages paid. Whenever
the Secretary of Labor has found, under 29 CFR
5.5(a)(1)(iv), that the wages of any laborer or mechanic
include the amount of costs reasonably anticipated in
providing benefits under a plan or program described in
section 1(b)(2)(B) of the Davis-Bacon Act, the Contractor
shall maintain records which show that the commitment to
provide such benefits is enforceable, that the plan or
program is financially responsible, and that the plan or
program has been communicated in writing to the laborers
or mechanics affected, and records which show the costs
anticipated or the actual cost incurred in providing such
benefits. Contractors employing apprentices or trainees
under approved programs shall maintain written evidence of

the registration of apprenticeship programs and certification
of trainee programs, the registration of the apprentices and
trainees, and the ratios and wage rates prescribed in the
applicable programs.
(2) (i) The Contractor shall submit weekly for each week in which
any contract work is performed a copy of all payrolls to the
Contracting Officer for transmission to HUD or its designee.
The payrolls submitted shall set out accurately and
completely all of the information required to be maintained
under subparagraph (c)(1) of this clause. This information
may be submitted in any form desired. Optional Form WH347 (Federal Stock Number 029-005-00014-1) is available
for this purpose and may be purchased from the
Superintendent of Documents, U.S. Government Printing
Office, Washington, D.C. 20402. The prime Contractor is
responsible for the submission of copies of payrolls by all
subcontractors. (Approved by the Office of Management
and Budget under OMB Control Number 1214-0149.)
(ii) Each payroll submitted shall be accompanied by a
“Statement of Compliance,” signed by the contractor or
subcontractor or his or her agent who pays or supervises
the payment of the persons employed under the contract
and shall certify the following:
(A) That the payroll for the payroll period contains the
information required to be maintained under paragraph
(c)(1) of this clause and that such information is
correct and complete;
(B) That each laborer or mechanic (including each
helper, apprentice, and trainee) employed on the
contract during the payroll period has been paid the
full weekly wages earned, without rebate, either
directly or indirectly, and that no deductions have been
made either directly or indirectly from the full wages
earned, other than permissible deductions as set forth
in 29 CFR Part 3; and
(C) That each laborer or mechanic has been paid not less
than the applicable wage rates and fringe benefits or
cash equivalents for the classification of work
performed, as specified in the applicable wage
determination incorporated into the contract.
(iii) The weekly submission of a properly executed
certification set forth on the reverse side of Optional Form
WH-347 shall satisfy the requirements for submission of
the “Statement of Compliance” required by subparagraph
(c)(2)(ii) of this clause.
(iv) The falsification of any of the above certifications may
subject the Contractor or subcontractor to civil or criminal
prosecution under Section 1001 of Title 18 and Section
3729 of Title 31 of the United States Code.
(3) The Contractor or subcontractor shall make the records required
under subparagraph (c)(1) available for inspection, copying, or
transcription by authorized representatives of HUD or its
designee, the Contracting Officer, or the Department of Labor
and shall permit such representatives to interview employees
during working hours on the job. If the Contractor or
subcontractor fails to submit the required records or to make
them available, HUD or its designee may, after written notice
to the Contractor, take such action as may be necessary to cause
the suspension of any further payment, advance, or guarantee
of funds. Furthermore, failure to submit the required records
upon request or to make such records available may be grounds
for debarment action pursuant to 29 CFR 5.12.

Page 5 of 7

Form HUD-5370-EZ (10/2006)

(d) Apprentices. Apprentices will be permitted to work at less than
the predetermined rate for the work they performed when they
are employed pursuant to and individually registered in a bona
fide apprenticeship program registered with the U.S.
Department of Labor, Employment and Training
Administration, Office of Apprenticeship Training, Employer
and Labor Services (OATELS), or with a State Apprenticeship
Agency recognized by OATELS, or if a person is employed in
his or her first 90 days of probationary employment as an
apprentice in such an apprenticeship program, who is not
individually registered in the program, but who has been
certified by OATELS or a State Apprenticeship Agency (where
appropriate) to be eligible for probationary employment as an
apprentice.
The allowable ratio of apprentices to journeymen on the job site
in any craft classification shall not be greater than the ratio
permitted to the Contractor as to the entire work force under the
registered program. Any worker listed on a payroll at an
apprentice wage rate, who is not registered or otherwise
employed as stated in this paragraph, shall be paid not less than
the applicable wage rate on the wage determination for the
classification of work actually performed. In addition, any
apprentice performing work on the job site in excess of the
ratio permitted under the registered program shall be paid not
less than the applicable wage rate on the wage determination
for the work actually performed. Where a contractor is
performing construction on a project in a locality other than
that in which its program is registered, the ratios and wage rates
(expressed in percentages of the journeyman’s hourly rate)
specified in the Contractor’s or subcontractor’s registered
program shall be observed. Every apprentice must be paid at
not less than the rate specified in the registered program for the
apprentice’s level of progress, expressed as a percentage of the
journeyman hourly rate specified in the applicable wage
determination. Apprentices shall be paid fringe benefits in
accordance with the provisions of the apprenticeship program.
If the apprenticeship program does not specify fringe benefits,
apprentices must be paid the full amount of fringe benefits
listed on the wage determination for the applicable
classification. If the Administrator of the Wage and Hour
Division determines that a different practice prevails for the
applicable apprentice classification, fringes shall be paid in
accordance with that determination. In the event OATELS, or a
State Apprenticeship Agency recognized by OATELS,
withdraws approval of an apprenticeship program, the
Contractor will no longer be permitted to utilize apprentices at
less than the applicable predetermined rate for the work
performed until an acceptable program is approved.
(e) Trainees. Except as provided in 29 CFR 5.16, trainees will not
be permitted to work at less than the predetermined rate for the
work performed unless they are employed pursuant to and
individually registered in a program which has received prior
approval, evidenced by formal certification by the U.S.
Department of Labor, Employment and Training
Administration. The ratio of trainees to journeymen on the job
site shall not be greater than permitted under the plan approved
by the Employment and Training Administration.
Every trainee must be paid at not less than the rate specified in
the approved program for the trainee’s level of progress,
expressed as a percentage of the journeyman hourly rate

specified in the applicable wage determination. Trainees shall
be paid fringe benefits in accordance with the provisions of the
trainee program. If the trainee program does not mention fringe
benefits, trainees shall be paid the full amount of fringe benefits
listed in the wage determination unless the Administrator of the
Wage and Hour Division determines that there is an
apprenticeship program associated with the corresponding
journeyman wage rate in the wage determination which
provides for less than full fringe benefits for apprentices. Any
employee listed on the payroll at a trainee rate who is not
registered and participating in a training plan approved by the
Employment and Training Administration shall be paid not less
than the applicable wage rate in the wage determination for the
classification of work actually performed. In addition, any
trainee performing work on the job site in excess of the ratio
permitted under the registered program shall be paid not less
than the applicable wage rate in the wage determination for the
work actually performed. In the event the Employment and
Training Administration withdraws approval of a training
program, the Contractor will no longer be permitted to utilize
trainees at less than the applicable predetermined rate for the
work performed until an acceptable program is approved.
(f) Equal Employment Opportunity. The utilization of
apprentices, trainees, and journeymen under this clause shall be
in conformity with the equal employment opportunity
requirements of Executive Order 11246, as amended, and 29
CFR Part 30.
(g) Compliance with Copeland Act Requirements. The
Contractor shall comply with the requirements of 29 CFR Part
3, which are hereby incorporated by reference in this contract.
(h) Contract Termination; Debarment. A breach of the labor
standards clauses in this contract may be grounds for
termination of the contract and for debarment as a Contractor
and a subcontractor as provided in 29 CFR 5.12.
(i) Compliance with Davis-Bacon and related Act
Requirements. All rulings and interpretations of the DavisBacon and related Acts contained in 29 CFR Parts 1, 3, and 5
are herein incorporated by reference in this contract.
(j) Disputes Concerning Labor Standards. Disputes arising out
of the labor standards provisions of this clause shall not be
subject to the general disputes clause of this contract. Such
disputes shall be resolved in accordance with the procedures of
the Department of Labor set forth in 29 CFR Parts 5, 6, and 7.
Disputes within the meaning of this clause include disputes
between the Contractor (or any of its subcontractors) and the
PHA, HUD, the U.S. Department of Labor, or the employees or
their representatives.
(k) Certification of Eligibility.
(1) By entering into this contract, the Contractor certifies that
neither it (nor he or she) nor any person or firm who has an
interest in the Contractor’s firm is a person or firm
ineligible to be awarded contracts by the United States
Government by virtue of section 3(a) of the Davis-Bacon
Act or 29 CFR 5.12(a)(1).
(2) No part of this contract shall be subcontracted to any person
or firm ineligible for award of a United States Government

Page 6 of 7

Form HUD-5370-EZ (10/2006)

contract by virtue of section 3(a) of the Davis-Bacon Act or
29 CFR 5.12(a)(1).
(3) The penalty for making false statements is prescribed in the
U. S. Criminal Code, 18 U.S.C. 1001.
(l) Subcontracts. The Contractor or subcontractor shall insert in
any subcontracts all the provisions contained in this clause, and
such other clauses as HUD or its designee may by appropriate
instructions require, and also a clause requiring the
subcontractors to include these provisions in any lower tier
subcontracts. The prime Contractor shall be responsible for the
compliance by any subcontractor or lower tier subcontractor
with all these provisions.
(m) Non-Federal Prevailing Wage Rates. Any prevailing wage
rate (including basic hourly rate and any fringe benefits),
determined under State law to be prevailing, with respect to any
employee in any trade or position employed under the contract,
is inapplicable to the contract and shall not be enforced against
the Contractor or any subcontractor, with respect to employees
engaged under the contract whenever such non-Federal
prevailing wage rate exceeds:
(i) the applicable wage rate determined by the Secretary of
Labor pursuant to the Davis-Bacon Act (40 U.S.C. 3141 et
seq.) to be prevailing in the locality with respect to such
trade;
(ii) an applicable apprentice wage rate based thereon specified
in an apprenticeship program registered with the U.S.
Department of Labor (DOL) or a DOL-recognized State
Apprenticeship Agency; or
(iii) an applicable trainee wage rate based thereon specified in
a DOL-certified trainee program.

Page 7 of 7

Form HUD-5370-EZ (10/2006)