HUD-5370 EZ General Contract Conditions for Small Construction/Devel

U.S. Department of Housing and Urban
Development
Office of Public and Indian Housing

General Contract Conditions for
Small Construction/Development
Contracts

OMB Approval No. 2577-0157 (exp. 11/30/2023)

S e e P ag e 7 f o r B u r d e n S ta t e m e n t
Applicability. The following contract clauses are applicable and
must be inserted into small construction/development contrac ts,
greater than $2,000 but not more than $250,000.
1. Definitions
Terms used in this form are the same as defined in form HUD-5370
2. Prohibition Against Liens
The Contractor is prohibited from placing a lien on the PHA's
property. This prohibition shall apply to all subcontractors at any
tier and all materials suppliers. The only liens on the PHA's
property shall be the Declaration of Trust or other liens approved
by HUD.
3. Disputes
(a) Except for disputes arising under the Labor Standards clauses,
all disputes arising under or relating to this contract, including
any claims for damages for the alleged breach thereof which are
not disposed of by agreement, shall be resolved under this
clause.
(b) All claims by the Contractor shall be made in writing and
submitted to the Contracting Officer for a written decision. A
claim by the PHA against the Contractor shall be subject to a
written decision by the Contracting Officer.
(c) The Contracting Officer shall, within 30 days after receipt of
the request, decide the claim or notify the Contractor of the
date by which the decision will be made.
(d) The Contracting Officer's decision shall be final unless the
Contractor (1) appeals in writing to a higher level in the PHA
in accordance with the PHA's policy and procedures, (2) refers
the appeal to an independent mediator or arbitrator, or (3) files
suit in a court of competent jurisdiction. Such appeal must be
made within 30 days after receipt of the Contracting Officer's
decision.
(e) The Contractor shall proceed diligently with performance of this
contract, pending final resolution of any request for relief, claim,
appeal, or action arising under or relating to the contract, and
comply with any decision of the Contracting Officer.
4. Default
(a) If the Contractor refuses or fails to prosecute the work, or any
separable part thereof, with the diligence that will insure its
completion within the time specified in this contract, or any
extension thereof, or fails to complete said work within this
time, the Contracting Officer may, by written notice to the
Contractor, terminate the right to proceed with the work (or
separable part of the work) that has been delayed. In the event,
the PHA may take over the work and complete it by contract or
otherwise, and may take possession of and use any materials,
equipment, and plant on the work site necessary for completing
the work. The Contractor and its sureties shall be liable for any
damage to the PHA resulting from the Contractor's refusal or
failure to complete the work within the specified time, whether
or not the Contractor's right to proceed with the work is
terminated. This liability includes any increased costs incurred
.
.

(b) The Contractor's right to proceed shall not be terminated or
the Contractor charged with damages under this clause if —
(1) The delay in completing the work arises from
unforeseeable causes beyond the control and without
the fault or negligence of the Contractor; and
(2) The Contractor, within 10 days from the beginning of such
delay notifies the Contracting Officer in writing of the
causes of delay. The Contracting Officer shall ascertain the
facts and the extent of the delay. If, in the judgment of the
Contracting Officer, the findings of Fact warrant such
action, time for completing the work shall be extended by
written modification to the contract The findings of the
Contracting Officer shall be reduced to a written decision
which shall be subject to the provisions of the Disputes
clause of this contract
(c) If, after termination of the Contractor's right to proceed, it is
determined that the Contractor was not in default, or that the
delay was excusable, the rights and obligation of the parties will
be the same as if the termination had been for convenience of
the PHA.
5. Termination for Convenience
(a) The Contracting Officer may terminate this contract in whole,
or in part, whenever the Contracting Officer determines that
such termination is in the best interest of the PHA. Any such
termination shall be effected by delivery to the Contractor of a
Notice of Termination specifying the extent to which the
performance of the work under the contract is terminated, and
the date upon which such termination becomes effective.
(b)If the performance of the work is terminated, either in whole or
in part, the PHA shall be liable to the Contractor for reasonable
and proper costs resulting from such termination upon the
receipt by the PHA of a properly presented claim setting out in
detail: (1) the total cost of the work performed to date of
termination less the total amount of contract payments made to
the Contractor; (2) the cost (including reasonable profit) of
settling and paying claims under subcontracts and material
orders for work performed and materials and supplies delivered
to the site, payment for which has not been made by the PHA to
the Contractor or by the Contractor to the subcontractor or
supplier; (3) the cost of preserving and protecting the work
already performed until the PHA or assignee takes possession
thereof or assumes responsibility therefore; (4) the actual or
estimated cost of legal and accounting services reasonably
necessary to prepare and present the termination claim to the
PHA; and (5) an amount constituting a reasonable profit on the
value of the work performed by the Contractor.
(c) The Contracting Officer will act on the Contractor's claim
within days (60 days unless otherwise indicated) of receipt of
the Contractor's claim.
(d)Any disputes with regard to this clause are expressly made
subject to the provisions of the Disputes clause of this contract
6. Insurance

(a) Before commencing work, the Contractor and each subcontractor shall furnish the PHA with certificates of insurance
showing the following insurance is in force and will insure all
operations under the Contract.
Page 1 of 7
Form HUD-5370-EZ (1/2014)

(1)
Workers' Compensation, in accordance with
state or Territorial Workers' Compensation laws.
(2) Commercial General Liability with a combined single limit
for bodily injury and property damage of not less than $ ________
[Contracting Officer insert amount] per occurrence to protect the
Contractor and each subcontractor against claims for bodily injury
or death and damage to the property of others. This shall cover the
use of all equipment, hoists, and vehicles on the site(s) not covered
by Automobile Liability under (3) below. If the Contractor has a
"claims-made" policy, then the following additional requirements
apply: the policy must provide a "retroactive date" which must be
on or before the execution date of the Contract; and the extended
reporting period may not be less than five years following the
completion date of the Contract
(3) Automobile Liability on owned and non -owned motor
vehicles used on the site(s) or in connection therewith for a
combined single limit for bodily injury and property damage of not
less than $ _____ [Contracting Officer insert amount] per
occurrence.
(b) Before commencing work, the Contractor shall furnish the PHA
with a certificate of insurance evidencing that Builder's Risk
(fire and extended coverage) Insurance on all work in place
and/or materials stored at the building site(s), including
foundations and building equipment, is in force. The Builder's
Risk Insurance shall be for the benefit of the Contractor and the
PHA as their interests may appear and each shall be named in
the policy or policies as an insured. The Contractor in installing
equipment supplied by the PHA shall carry insurance on such
equipment from the time the Contractor takes possession
thereof until the Contract work is accepted by the PHA. The
Builder's Risk Insurance need not be carried on excavations,
piers, footings, or foundations until such time as work on the
superstructure is started. It need not be carried on landscape
work. Policies shall furnish coverage at all times for the full
cash value of all completed construction, as well as materials in
place and/or stored at the site(s), whether or not partial payment
has been made by the PHA. The Contractor may terminate this
insurance on buildings as of the date taken over for occupancy
by the PHA. The Contractor is not required to carry Builder's
Risk Insurance for modernization work which does not involve
structural alterations or additions and where the PHA's existing
fire and extended coverage policy can be endorsed to include
such work.
(c) All insurance shall be carried with companies which are
financially responsible and admitted to do business in the State
in which the project is located. If any such insurance is due to
expire during the construction period, the Contractor (including
subcontractors, as applicable) shall not permit the coverage to
lapse and shall furnish evidence of coverage to the Contracting
Officer. All certificates of insurance, as evidence of coverage,
shall provide that no coverage may be canceled or non-renewed
by the insurance company until at least 30 days prior written
notice has been given to the Contracting Officer.
7. Contract Modifications
(a) Only the Contracting Officer has authority to modify any
term or condition of this contract. Any contract modification
shall be authorized in writing.
(b) The Contracting Officer may modify the contract unilaterally
(1) pursuant to a specific authorization stated in a contract
clause (e.g., Changes); or (2) for administrative matters which

Page 2 of 7

do not change the rights or responsibilities of the parties (e.g.,
change in the PHA address). All other contract modifications
shall be in the form of supplemental agreements signed by the
Contractor and the Contracting Officer.
(c) When a proposed modification requires the approval of HUD
prior to its issuance (e.g., a change order that exceeds the
PHA's approved threshold), such modification shall not be
effective until the required approval is received by the PHA.
8. Changes
(a) The Contracting Officer may, at any time, without notice to the
sureties, by written order designated or indicated to be a change
order, make changes in the work within the general scope of the
contract including changes:
(1) In the specifications (including drawings and designs);
(2) In the method or manner of performance of the work;
(3) PHA-furnished facilities, equipment, materials, services,
or site; or,
(4) Directing the acceleration in the performance of the work (b) Any
other written order or oral order (which, as used in this paragraph
(b), includes direction, instruction, interpretation, or
determination) from the Contracting Officer that causes a change
shall be treated as a change order under this clause; provided, that
the Contractor gives the Contracting Officer written notice stating
(1) the date, circumstances and source of the order and (2) that the
Contractor regards the order as a change order.
(c) Except as provided in this clause, no order, statement or conduct
of the Contracting Officer shall be treated as a change under this
clause or entitle the Contractor to an equitable adjustment.
(d) Many change under this clause causes an increase or decrease in
the Contractor's cost of, or the time required for the performance
of any part of the work under this contract, whether or not
changed by any such order, the Contracting Officer shall make
an equitable adjustment and modify the contract in writing.
However, except for a adjustment based on defective
specifications, no proposal for any change under paragraph (b)
above shall be allowed for any costs incurred more than 20 days
(5 days for oral orders) before the Contractor gives written
notice as required. In the case of defective specifications for
which the PHA is responsible, the equitable adjustment shall
include any increased cost reasonably incurred by the Contractor
in attempting to comply with the defective
specifications.
( ) The Contractor must assert its right to an adjustment under this
clause within 30 days after (1) receipt of a written change order
under paragraph (a) of this clause, or (2) the fiunishing of a
written notice under paragraph (b) of this clause, by submitting a
written statement describing the general nature and the amount of
the proposal. If the facts justify it, the Contracting Officer may
extend the period for submission. The proposal may be included
in the notice required under paragraph (b) above. No proposal by
the Contractor for an equitable adjustment shall be allowed if
asserted after final payment under this
contract
(e) The Contractor's written proposal for equitable adjustment shall
be submitted in the form of a lump sum proposal supported
with an itemized breakdown of all increases and decreases in
the contract in at least the following details:
(1) Direct Costs. Materials (list individual items, the quantity
and unit cost of each, and the aggregate cost); Transportation and delivery costs associated with materials; Labor

Form HUD-5370-EZ (1/2014)

breakdowns by hours or unit costs (identified with specific
work to be performed); Construction equipment exclusively
necessary for the change; Costs of preparation and/ or
revision to shop drawings resulting from the change;
Worker's Compensation and Public Liability Insurance;
Employment taxes under FICA and FUTA; and, Bond Costs
- when size of change warrants revision.
(2)Indirect Costs. Indirect costs may include overhead, general
and administrative expenses, and fringe benefits not
normally treated as direct costs.
(3)Profit. The amount of profit shall be negotiated and may
vary according to the nature, extent, and complexity of the
work required by the change.
The allowability of the direct and indirect costs shall be determined
in accordance with the Contract Cost Principles and Procedures for
Commercial Firms in Part 31 of the Federal Acquisition Regulation
(48 CFR 1-31), as implemented by HUD Handbook 2210.18, in
effect on the date of this contract. The Contractor shall not be
allowed a profit on the profit received by any subcontractor.
Equitable adjustments for deleted work shall include a credit for
profit and may include a credit for indirect costs. On proposals
covering both increases and decreases in the amount of the contract,
the application of indirect costs and profit shall be on the net-change
in direct costs for the Contractor or subcontractor
performing the work
(g) The Contractor shall include in the proposal its request for time
extension (if any), and shall include sufficient information and
dates to demonstrate whether and to what extent the change will
delay the completion of the contract in its entirety.
(h) The Contracting Officer shall act on proposals within 30
days after their receipt, or notify the Contractor of the date
when such action will be taken.
(i) Failure to reach an agreement on any proposal shall be a dispute
under the clause entitled Disputes herein. Nothing in this
clause, however, shall excuse the Contractor from proceeding
with the contract as changed.
(j) Except in an emergency endangering life or property, no change
shall be made by the Contractor without a prior order from the
Contracting Officer.
9. Examination and Retention of Contractor's Records
The HA, HUD, or Comptroller General of the United States, or
any of their duly authorized representatives shall, until three years
after final payment under this contract, have access to and the right
to examine any of the Contractor's directly pertinent books,
documents, papers, or other records involving transactions related
to this contract for the purpose of making audit, examination,
excerpts, and transcriptions.
10.
Rights in Data and Patent Rights (Ownership
and Proprietary Interest)
The HA shall have exclusive ownership of, all proprietary interest
in, and the right to full and exclusive possession of all information,
materials, and documents discovered or produced by Contractor
pursuant to the terms of this Contract, including but not limited to
reports, memoranda or letters concerning the research and
reporting tasks of this Contract.
11.

Energy Efficiency

The Contractor shall comply with all mandatory standards and
policies relating to energy efficiency which are contained in the
energy conservation plan issued in compliance with the Energy
Policy and Conservation Act (Pub.L. 94-163) for the State in which
the work under this contract is performed.
12. Procurement of Recovered Materials
(a) In accordance with Section 6002 of the Solid Waste Disposal
Act, as amended by the Resource Conservation and Recovery
Act, the Contractor shall procure items designated in guidelines
of the Environmental Protection Agency (EPA) at 40 CFR Part
247 that contain the highest percentage of recovered materials
practicable, consistent with maintaining a satisfactory level of
competition. The Contractor shall procure items designated in
the EPA guidelines that contain the highest percentage of
recovered materials practicable unless the Contractor
determines that such items: (1) are not reasonably available in a
reasonable period of time; (2) fail to meet reasonable
performance standards, which shall be determined on the basis
of the guidelines of the National Institute of Standards and
Technology, if applicable to the item; or (3) are only available
at an unreasonable price.
(b) Paragraph (a) of this clause shall apply to items purchased
under this contract where: (1) the Contractor purchases in
excess of $10,000 of the item under this contract; or (2) during
the preceding Federal fiscal year, the Contractor: (i) purchased
any amount of the items for use under a contract that was
funded with Federal appropriations and was with a Federal
agency or a State agency or agency of a political subdivision of
a State; and (ii) purchased a total of in excess of $10,000 of the
item both under and outside that contract
13. Training and Employment Opportunities for Residents in the
Project Area (Section 3, HUD Act of 1968; 24 CFR 75)
(a) The work to be performed under this contract is subject to the
requirements of section 3 of the Housing and Urban
Development Act of 1968, as amended, 12 U.S.C. 1701u
(section 3). The purpose of section 3 is to ensure that
employment and other economic opportunities generated by
HUD assistance or HUD-assisted projects covered by section 3,
shall, to the greatest extent feasible, be directed to low- and
very low-income persons, particularly persons who are
recipients of HUD assistance for housing.
(b) The parties to this contract agree to comply with HUD's
regulations in 24 CFR Part 75, which implement section 3. As
evidenced by their execution of this contract, the parties to this
contract certify that they are under no contractual or other
impediment that would prevent them from complying with the
Part 75 regulations.
(c) The contractor agrees to send to each labor organization or
representative of workers with which the contractor has a
collective bargaining agreement or other understanding, if any,
a notice advising the labor organization or workers'
representative of the contractor's commitments under this
section 3 clause, and will post copies of the notice in
conspicuous places at the work site where both employees and
applicants for training and employment positions can see the
notice. The notice shall describe the section 3prioritization
requirements , and shall state the minimum percentages of labor
hour requirements established in the Benchmark Notice (FR6085-N-04).

Page 3 of 7

Form HUD-5370-EZ (1/2014)

.
(d) The contractor agrees to include this section 3 clause in every
subcontract subject to compliance with regulations in 24 CFR
Part 75, and agrees to take appropriate action, as provided in an
applicable provision of the subcontract or in this section 3
clause, upon a finding that the subcontractor is in violation of
the regulations in 24 CFR Part 75. The contractor will not
subcontract with any subcontractor where the contractor has
notice or knowledge that the subcontractor has been found in
violation of the regulations in 24 CFR Part 75.
(e) .Noncompliance with HUD's regulations in 24 CFR Part 75
may result in sanctions, termination of this contract for default,
and debarment or suspension from future HUD assisted
contracts.
(f) Contracts, subcontracts, grants, or subgrants subject to
Section 7(b) of the Indian Self-Determination and Education
Assistance Act (25 U.S.C. 5307(b)) or subject to tribal
preference requirements as authorized under 101(k) of the
Native American Housing Assistance and Self-Determination
Act (25 U.S.C. 4111(k)) must provide preferences in
employment, training, and business opportunities to Indians
and Indian organizations, and are therefore not subject to the
requirements of 24 CFR Part 75.
14. Labor Standards - Davis-Bacon and Related Acts
(a) Minimum Wages.
(1) All laborers and mechanics employed under this contract in
the construction or development of the project(s) involved will
be paid unconditionally and not less often than once a week,
and without subsequent deduction or rebate on any account
(except such payroll deductions as are permitted by regulations
issued by the Secretary of Labor under the Copeland Act (29
CFR Part 3)), the full amount of wages and bona fide fringe
benefits (or cash equivalents thereof) due at time of payment
computed at rates not less than those contained in the wage
determination of the Secretary of Labor which is attached
hereto and made a part hereof, regardless of any contractual
relationship which may be alleged to exist between the
Contractor and such laborers and mechanics. Contributions
made or costs reasonably anticipated for bona fide fringe
benefits under Section 1(b)(2) of the Davis-Bacon Act on
behalf of laborers or mechanics are considered wages paid to
such laborers or mechanics, subject to the provisions of 29 CFR
5.5(a)(1)(iv); also, regular contributions made or costs incurred
for more than a weekly period (but not less often than
quarterly) under plans, funds, or programs which cover the
regular weekly period, are deemed to be constructively made or
incurred during such weekly period. Such laborers and
mechanics shall be paid the appropriate wage rate and fringe
benefits in the wage determination for the classification of work
actually performed, without regard to skill, except as provided
in 29 CFR 5.5(a)(4). Laborers or mechanics performing work in
more than one classification may be compensated at the rate
specified for each classification for the time actually worked
therein; provided, that the employer's payroll records accurately
set forth the time spent in each classification in which work is
performed. The wage determination (including any additional
classification and wage rates conformed under 29 CFR
5.5(a)(1)(ii) and the Davis-Bacon poster (WH-1321) shall be
posted at all times by the Contractor and its subcontractors at
the site of the work in

Page 4 of 7

a prominent and accessible place where it can be easily
seen by the workers.
(2) (i) Any class of laborers or mechanics, including helpers,
which is not listed in the wage determination and which
is to be employed under the contract shall be classified
in conformance with the wage determination. HUD
shall approve an additional classification and wage rate
and fringe benefits therefor only when all the following
criteria have been
met:
(a) The work to be performed by the classification
requested is not performed by a classification in
the wage determination; and
(b) The classification is utilized in the area by
the construction industry; and
(c) The proposed wage rate, including any bona fide
fringe benefits, bears a reasonable relationship to
the wage rates contained in the wage
detemination.
(ii) If the Contractor and the laborers and mechanics to be
employed in the classification (if known), or their
representatives, and HUD or its designee agree on the
classification and wage rate (including the amount
designated for fringe benefits where appropriate), a
report of the action shall be sent by HUD or its
designee to the Administrator of the Wage and Hour
Division, Employee Standards Administration, U.S.
Department of Labor, Washington, DC 20210. The
Administrator, or an authorized representative, will
approve, modify, or disapprove every additional
classification action within 30 days of receipt and so
advise HUD or its designee or will notify HUD or its
designee within the 30-day period that additional time
is necessary.
(iii) In the event the Contractor, the laborers or mechanics
to be employed in the classification or their
representatives, and HUD or its designee do not agree
on the proposed classification and wage rate (including
the amount designated for fringe benefits, where
appropriate), HUD or its designee shall refer the
questions, including the views of all interested parties
and the recommendation of HUD or its designee, to the
Administrator of the Wage and Hour Division for
determination. The Administrator, or an authorized
representative, will issue a determination within 30
days of receipt and so advise HUD or its designee or
will notify HUD or its designee within the 30-day
period that additional time is necessary.
(iv) The wage rate (including fringe benefits where
appropriate) determined pursuant to subparagraphs
(a)(2)(ii) or (iii) of this clause shall be paid to all
workers performing work in the classification
under this contract from the first day on which
work is performed in the classification.
(3) Whenever the minimum wage rate prescribed in the
contract for a class of laborers or mechanics includes a
fringe benefit which is not expressed as an hourly rate,
the Contractor shall either pay the benefit as stated in the
wage determination or shall pay another bona fide fringe
benefit or an hourly cash equivalent thereof.
(4) If the Contractor does not make payments to a trustee
or other third person, the Contractor may consider as part
Form HUD-5370-EZ (1/2014)

of the wages of any laborer or mechanic the amount of
any costs reasonably anticipated in providing bona fide
fringe benefits under a plan or program; provided, that
the Secretary of Labor has found, upon the written
request of the Contractor, that the applicable standards
of the Davis-Bacon Act have been met. The Secretary of
Labor may require the Contractor to set aside in a
separate account assets for the meeting of obligations
under the plan or program.
(b) Withholding of Funds. HUD or its designee shall, upon its
own action or upon written request of an authorized
representative of the Department of Labor, withhold or
cause to be withheld from the Contractor under this
contract or any other Federal contract with the same
prime Contractor, or any other Federally-assisted contract
subject to Davis-Bacon prevailing wage requirements,
which is held by the same prime Contractor, so much of
the accrued payments or advances as may be considered
necessary to pay laborers and mechanics, including
apprentices, trainees, and helpers, employed by the
Contractor or any subcontractor the full amount of wages
required by the contract. In the event of failure to pay any
laborer or mechanic, including any apprentice, trainee, or
helper, employed or working in the construction or
development of the project, all or part of the wages
required by the contract, HUD or its designee may, after
written notice to the Contractor, take such action as may
be necessary to cause the suspension of any further
payment, advance, or guarantee of funds until such
violations have ceased. HUD or its designee may, after
written notice to the Contractor, disburse such amounts
withheld for and on account of the Contractor or
subcontractor to the respective employees to whom they
are due.
(c) Payrolls and Basic Records.
(1) Payrolls and basic records relating thereto shall be
maintained by the Contractor during the course of the work
and preserved for a period of three years thereafter for all
laborers and mechanics working in the construction or
development of the project. Such records shall contain the
name, address, and social security number of each such
worker, his or her correct classification, hourly rates of
wages paid (including rates of contributions or costs
anticipated for bona fide fringe benefits or cash equivalents
thereof of the types described in section 1(b)(2)(B) of the
Davis-Bacon Act), daily and weekly number of hours
worked, deductions made, and actual wages paid. Whenever
the Secretary of Labor has found, under 29 CFR
5.5(a)(1)(iv), that the wages of any laborer or mechanic
include the amount of costs reasonably anticipated in
providing benefits under a plan or program described in
section 1(b)(2)(B) of the Davis-Bacon Act, the Contractor
shall maintain records which show that the commitment to
provide such benefits is enforceable, that the plan or
program is financially responsible, and that the plan or
program has been communicated in writing to the laborers or
mechanics affected, and records which show the costs
anticipated or the actual cost incurred in providing such
benefits. Contractors employing apprentices or trainees
under approved programs shall maintain written evidence of

the registration of apprenticeship programs and certification
of trainee programs, the registration of the apprentices and
trainees, and the ratios and wage rates prescribed in the
applicable programs.
(2) (i) The Contractor shall submit weekly for each week in which
any contract work is performed a copy of all payrolls to the
Contracting Officer for transmission to HUD or its designee.
The payrolls submitted shall set out accurately and
completely all of the information required to be maintained
under subparagraph (c)(1) of this clause. This information
may be submitted in any form desired. Optional Form WH347 (Federal Stock Number 029-005-00014-1) is available
for this purpose and may be purchased from the
Superintendent of Documents, U.S. Government Printing
Office, Washington, D.C. 20402. The prime Contractor is
responsible for the submission of copies of payrolls by all
subcontractors. (Approved by the Office of Management and
Budget under OMB Control Number 1214-0149.)
(ii) Each payroll submitted shall be accompanied by a
"Statement of Compliance," signed by the contractor or
subcontractor or his or her agent who pays or supervises
the payment of the persons employed under the contract
and shall certify the following:
(A) That the payroll for the payroll period contains the
information required to be maintained under paragraph
(c)(1) of this clause and that such information is
correct and complete;
(B) That each laborer or mechanic (including each
helper, apprentice, and trainee) employed on the
contract during the payroll period has been paid the
full weekly wages earned, without rebate, either
directly or indirectly, and that no deductions have
been made either directly or indirectly from the full
wages earned, other than permissible deductions as
set forth in 29 CFR Part 3; and
(C) That each laborer or mechanic has been paid not
less than the applicable wage rates and fringe
benefits or cash equivalents for the classification of
work performed, as specified in the applicable wage
determination incorporated into the contract
(iii) The weekly submission of a properly executed
certification set forth on the reverse side of Optional Form
WH-347 shall satisfy the requirements for submission of
the "Statement of Compliance" required by subparagraph
(c)(2)(ii) of this clause.
(iv) The falsification of any of the above certifications may
subject the Contractor or subcontractor to civil or criminal
prosecution under Section 1001 of Title 18 and Section
3729 of Title 31 of the United States Code.
(3) The Contractor or subcontractor shall make the records required
under subparagraph (c)(1) available for inspection, copying, or
transcription by authorized representatives of HUD or its
designee, the Contracting Officer, or the Department of Labor
and shall permit such representatives to interview employees
during working hours on the job. If the Contractor or
subcontractor fails to submit the required records or to make
them available, HUD or its designee may, after written notice to
the Contractor, take such action as may be necessary to cause the
suspension of any further payment, advance, or guarantee of
funds. Furthermore, failure to submit the required records upon
request or to make such records available may be grounds for
debarment action pursuant to 29 CFR 5.12.

Page 5 of 7

Form HUD-5370-EZ (1/2014)

(d) Apprentices. Apprentices will be permitted to work at less
than the predetermined rate for the work they performed when
they are employed pursuant to and individually registered in a
bona fide apprenticeship program registered with the U.S.
Department of Labor, Employment and Training
Administration, Office of Apprenticeship Training, Employer
and Labor Services (OATELS), or with a State Apprenticeship
Agency recognized by OATELS, or if a person is employed in
his or her first 90 days of probationary employment as an
apprentice in such an apprenticeship program, who is not
individually registered in the program, but who has been
certified by OATELS or a State Apprenticeship Agency (where
appropriate) to be eligible for probationary employment as an
apprentice.
The allowable ratio of apprentices to journeymen on the job
site in any craft classification shall not be greater than the ratio
permitted to the Contractor as to the entire work force under
the registered program. Any worker listed on a payroll at an
apprentice wage rate, who is not registered or otherwise
employed as stated in this paragraph, shall be paid not less
than the applicable wage rate on the wage determination for
the classification of work actually performed. In addition, any
apprentice performing work on the job site in excess of the
ratio permitted under the registered program shall be paid not
less than the applicable wage rate on the wage determination
for the work actually performed. Where a contractor is
performing construction on a project in a locality other than
that in which its program is registered, the ratios and wage
rates (expressed in percentages of the journeyman's hourly
rate) specified in the Contractor's or subcontractor's registered
program shall be observed. Every apprentice must be paid at
not less than the rate specified in the registered program for
the apprentice's level of progress, expressed as a percentage of
the journeyman hourly rate specified in the applicable wage
determination. Apprentices shall be paid fringe benefits in
accordance with the provisions of the apprenticeship program.
If the apprenticeship program does not specify fringe benefits,
apprentices must be paid the full amount of fringe benefits
listed on the wage determination for the applicable
classification. If the Administrator of the Wage and Hour
Division determines that a different practice prevails for the
applicable apprentice classification, fringes shall be paid in
accordance with that determination. In the event OATELS, or
a State Apprenticeship Agency recognized by OATELS,
withdraws approval of an apprenticeship program, the
Contractor will no longer be permitted to utilize apprentices at
less than the applicable predetermined rate for the work
performed until an acceptable program is approved.
(e) Trainees. Except as provided in 29 CFR 5.16, trainees will not
be permitted to work at less than the predetermined rate for the
work performed unless they are employed pursuant to and
individually registered in a program which has received prior
approval, evidenced by formal certification by the U.S.
Department of Labor, Employment and Training
Administration. The ratio of trainees to journeymen on the job
site shall not be greater than permitted under the plan
approved by the Employment and Training Administration.
Every trainee must be paid at not less than the rate specified in
the approved program for the trainee's level of progress,
expressed as a percentage of the journeyman hourly rate

specified in the applicable wage determination. Trainees shall be
paid fringe benefits in accordance with the provisions of the
trainee program. If the trainee program does not mention fringe
benefits, trainees shall be paid the full amount of fringe benefits
listed in the wage determination unless the Administrator of the
Wage and Hour Division determines that there is an
apprenticeship program associated with the corresponding
journeyman wage rate in the wage determination which provides
for less than full fringe benefits for apprentices. Any employee
listed on the payroll at a trainee rate who is not registered and
participating in a training plan approved by the Employment and
Training Administration shall be paid not less than the
applicable wage rate in the wage determination for the
classification of work actually performed. In addition, any
trainee performing work on the job site in excess of the ratio
permitted under the registered program shall be paid not less
than the applicable wage rate in the wage determination for the
work actually performed. In the event the Employment and
Training Administration withdraws approval of a training
program, the Contractor will no longer be permitted to utilize
trainees at less than the applicable predetermined rate for the
work performed until an acceptable program is approved.
(f) Equal Employment Opportunity. The utilization of
apprentices, trainees, and journeymen under this clause shall
be in conformity with the equal employment opportunity
requirements of Executive Order 11246, as amended, and 29
CFR Part 30.
(g) Compliance with Copeland Act Requirements. The Contractor
shall comply with the requirements of 29 CFR Part 3, which
are hereby incorporated by reference in this contract
(h) Contract Termination; Debarment. A breach of the labor
standards clauses in this contract may be grounds for
termination of the contract and for debarment as a
Contractor and a subcontractor as provided in 29 CFR 5.12.
(i) Compliance with Davis-Bacon and related Act
Requirements. All rulings and interpretations of the DavisBacon and related Acts contained in 29 CFR Parts 1, 3, and
5 are herein incorporated by reference in this contract
(j) Disputes Concerning Labor Standards. Disputes arising out of
the labor standards provisions of this clause shall not be subject
to the general disputes clause of this contract. Such disputes
shall be resolved in accordance with the procedures of the
Department of Labor set forth in 29 CFR Parts 5, 6, and 7.
Disputes within the meaning of this clause include disputes
between the Contractor (or any of its subcontractors) and the
PHA, HUD, the U.S. Department of Labor, or the employees or
their representatives.
(k) Certification of Eligibility.
(1)By entering into this contract, the Contractor certifies that
neither it (nor he or she) nor any person or firm who has an
interest in the Contractor's firm is a person or firm
ineligible to be awarded contracts by the United States
Government by virtue of section 3(a) of the Davis-Bacon
Act or 29 CFR 5.12(a)(1).
(2)No part of this contract shall be subcontracted to any person
or firm ineligible for award of a United States Government

Page 6 of 7

Form HUD-5370-EZ (1/2014)

contract by virtue of section 3(a) of the Davis-Bacon Act or
29 CFR 5.12(a)(1).
(3) The penalty for making false statements is prescribed in the
U. S. Criminal Code, 18 U.S.C. 1001.
(1) Subcontracts. The Contractor or subcontractor shall insert in
any subcontracts all the provisions contained in this clause, and
such other clauses as HUD or its designee may by appropriate
instructions require, and also a clause requiring the
subcontractors to include these provisions in any lower tier
subcontracts. The prime Contractor shall be responsible for the
compliance by any subcontractor or lower tier subcontractor
with all these provisions.
(m) Non-Federal Prevailing Wage Rates. Any prevailing wage
rate (including basic hourly rate and any fringe benefits),
determined under State law to be prevailing, with respect to any
employee in any trade or position employed under the contract,
is inapplicable to the contract and shall not be enforced against
the Contractor or any subcontractor, with respect to employees
engaged under the contract whenever such non-Federal
prevailing wage rate exceeds:
(i) the applicable wage rate determined by the Secretary of
Labor pursuant to the Davis-Bacon Act (40 U.S.C. 3141 et
seq.) to be prevailing in the locality with respect to such
trade;
(ii) an applicable apprentice wage rate based thereon specified
in an apprenticeship program registered with the U.S.
Department of Labor (DOL) or a DOL-recognized State
Apprenticeship Agency; or
(iii) an applicable trainee wage rate based thereon specified in
a DOL-certified trainee program.
Public reporting burden for this collection of information is estimated to average 1 hour. This includes the time for
collecting, reviewing, and reporting the data. The information requested is required to obtain a benefit. This form
includes those clauses required by OMB's common rule on grantee procurement, implemented at HUD in 2 CFR 200, and
those requirements set forth in Section 3 of the Housing and Urban Development Act of 1968 and its amendment by the
Housing and Community Development Act of 1992, implemented by HUD at 24 CFR Part 7575. The form is required for
construction contracts awarded by Public Housing Agencies (PHAs). The form is used by Housing Authorities in so
licitations to provide necessary contract clauses. If the form were not used, PHAs would be unable to enforce their
contracts.. There are no assurances of confidentiality. HUD may not conduct or sponsor, and an applicant is not required
to respond to a collection of information unless it displays a currently valid OMB control number.

Page 7 of 7

Form HUD-5370-EZ (1/2014)